Common use of Cooperation and Harmony on Site Clause in Contracts

Cooperation and Harmony on Site. 9.1.1 This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the Unions, and working with the Community Workforce Coordinator, together with the Contractors, to complete the construction of the Project economically, efficiency, continuously and without any interruption, delays or work stoppages. 9.1.2 The Community Workforce Coordinator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 or 7. 9.1.3 The Community Workforce Coordinator shall oversee the processing of grievances under this Article and Article 6, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement CSWPA is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Community Workforce Project Labor Coordinator, together with the Contractors, to complete the construction of the Project Work economically, efficiencyefficiently, continuously and without any interruption, delays or work stoppages. 9.1.2 (b) The Community Workforce Project Labor Coordinator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 8 or 710. 9.1.3 (c) The Community Workforce Project Labor Coordinator shall oversee observe the processing of grievances under this Article and Article 6Articles 8 and 9, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties Parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Community Workforce Project Labor Coordinator, together with the Contractors, to complete the construction of the Project economically, efficiencyefficiently, continuously and without any interruption, delays or work stoppages. 9.1.2 (b) The Community Workforce Project Labor Coordinator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 VII or 7VIII. 9.1.3 (c) The Community Workforce Project Labor Coordinator shall oversee the processing of grievances under this Article and Article 6Articles VII and VIII, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement CBA is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Community Workforce Project Labor Coordinator, together with the Contractors, to complete the construction of the Project Work economically, efficiencyefficiently, continuously and without any interruption, delays or work stoppages. 9.1.2 (b) The Community Workforce Project Labor Coordinator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 8 or 710. 9.1.3 (c) The Community Workforce Project Labor Coordinator shall oversee observe the processing of grievances under this Article and Article 6Articles 8 and 10, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties Parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Community Workforce Project Labor Coordinator, together with the Contractors, to complete the construction of the Project Work economically, efficiencyefficiently, continuously continuously, and without any interruption, delays delays, or work stoppages. 9.1.2 (b) The Community Workforce Project Labor Coordinator, the Contractors, Unions, and employees employees, collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Project Work, and agree to resolve all disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. 9.1.3 (c) The Community Workforce Project Labor Coordinator shall oversee observe the processing of grievances under this Article and Article 6Articles 7 and 8, including the scheduling and arrangements arrangement of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties Parties to any pending grievance to insure ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement CBA is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Community Workforce Project Labor Coordinator, together with the Contractors, to complete the construction of the Project Covered Projects economically, efficiencyefficiently, continuously continuously, and without any interruption, delays delays, or work stoppages. 9.1.2 (b) The Community Workforce Project Labor Coordinator, the Contractors, Unions, and employees employees, collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project of Covered Work, and agree to resolve all disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. 9.1.3 (c) The Community Workforce Project Labor Coordinator shall oversee observe the processing of grievances under this Article and Article 6Articles 7 and 8, including the scheduling and arrangements arrangement of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties Parties to any pending grievance to insure ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. 9.1.1 (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the Unions, and working with the Community Workforce Coordinator, together with the Contractors, to complete the construction of the Project economically, efficiency, continuously and without any interruption, delays or work stoppages. 9.1.2 (b) The Community Workforce Coordinator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. 9.1.3 (c) The Community Workforce Coordinator shall oversee the processing of grievances under this Article and Article 6Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.