Common use of Cooperation and Harmony on Site Clause in Contracts

Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the City and the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages. (b) The Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 or 7. (c) The Unions and/or Council shall oversee the processing of grievances under this Article and Articles 6 and 7, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the City and District, together with the Contractors, to complete the construction of the Project economically, efficientlyefficiency, continuously and without any interruption, delays or work stoppages. (b) The District, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. (c) The Unions and/or Council shall oversee the processing of grievances under this Article and Articles 6 7 and 78, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) 10.1.1 This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the City and CWA Administrator, together with the Contractors, to complete the construction of the Project economically, efficiently, continuously and without any interruption, delays or work stoppages. (b) 10.1.2 The CWA Administrator, the Contractors, Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. (c) 10.1.3 The Unions and/or Council CWA Administrator shall oversee the processing of grievances under this Article and Articles 6 7 and 78, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal parties to any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the City and District, together with the Contractors, to complete the construction of the Project economically, efficientlyefficiency, continuously continuously, and without any interruption, delays delay, or work stoppages. (b) The District, the Contractors, and the Unions, and employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance Project Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 6 7 or 78. (c) The Unions and/or Council District shall oversee the processing of grievances under this Article and Articles 6 7 and 78, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator Arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; , provided, however, that it is the responsibility of the principal parties to of any pending grievance to insure the time limits and deadlines are met.