Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Performance of the Work The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project.
Cost of Services Except to the extent specified otherwise in the Agreement, all costs of performing the Services are included in the Contract Price and TOMRA shall not be entitled to any further payment in respect thereof.
Performance Testing 7.2.1 The Design-Builder shall direct and supervise the tests and, if necessary, the retests of the Plant using Design-Builder’s supervisory personnel and the Air Emissions Tester shall conduct the air emissions test, in each case, in accordance with the testing procedures set forth in Exhibit A (the “Performance Tests”), to demonstrate, at a minimum, compliance with the Performance Guarantee Criteria. Owner is responsible for obtaining Air Emissions Tester and for ensuring Air Emissions Tester’s timely performance. Design-Builder shall cooperate with the Air Emissions Tester to facilitate performance of all air emissions tests. Design-Builder shall not be held responsible for the actions of Owner’s employees and third parties involved in the Performance Testing, including but not limited to Air Emissions Tester.
7.2.2 No later than thirty (30) Days prior to the earlier of the Scheduled Substantial Completion Date or Substantial Completion, Design-Builder shall provide to Owner for review a detailed testing plan for the Performance Tests (other than for air emissions). Owner and Design-Builder shall agree upon a testing plan that shall be consistent with the Performance Test Protocol contained in Exhibit A hereto. After such agreement has been reached, Design-Builder shall notify the Owner five (5) business days prior to the date Design-Builder intends to commence the Performance Tests and shall notify the Owner upon commencement of the Performance Tests. Owner and Independent Engineer each have the right to witness all testing, including the Performance Tests and any equipment testing, whether at the Site or at the Subcontractor’s or equipment supplier’s premises during the course of this Agreement. Notwithstanding the foregoing sentence, Owner shall bear the costs of providing a witness to any such testing and all such witnesses shall comply at all times with Design-Builder’s, Subcontractor’s or equipment supplier’s safety and security procedures and other reasonable requirements, and otherwise conduct themselves in a manner that does not interfere with Design-Builder’s, Subcontractor’s or equipment supplier’s activities or operations.
7.2.3 Design-Builder shall provide to Owner a Performance Test report (excluding results from air emissions testing), including all applicable test data, calculations and certificates indicating the results of the Performance Tests and, within five (5) business days of Owner’s receipt of such results, Owner, Independent Engineer and Design-Builder will jointly inspect such Work and review the results of the Performance Tests to verify that the Performance Guarantee Criteria have been met. If Owner or Independent Engineer reasonably determines that the Performance Guarantee Criteria have not been met, Owner shall notify Design-Builder the reasons why Owner determined that the Performance Guarantee Criteria have not been met and Design-Builder shall promptly take such action or perform such additional work as will achieve the Performance Guarantee Criteria and shall issue to the Owner another notice in accordance with Section 7.2.2; provided however that if the notice relates to a retest, the notice may be provided no less than two (2) business days prior to the Performance Tests. Such procedure shall be repeated as necessary until Owner and Independent Engineer verifies that the Performance Guarantee Criteria have been met.
7.2.4 If Owner, for whatever reason, prevents Design-Builder from demonstrating the Performance Guarantee Criteria within thirty (30) Days of Design-Builder’s notice that the Plant is ready for Performance Testing, then Design-Builder shall be excused from demonstrating compliance with the Performance Guarantee Criteria during such period of time that Design-Builder is prevented from demonstrating compliance with the Performance Guarantee Criteria; provided however that Design-Builder will be deemed to have fulfilled all of its obligations to demonstrate that the Plant meets the Performance Guarantee Criteria should such period of time during which Design-Builder is prevented from demonstrating the Performance Criteria exceed thirty (30) Days or extend beyond the Final Completion Date.
Mileage Measurement Where required, the mileage measurement for LIS rate elements is determined in the same manner as the mileage measurement for V&H methodology as outlined in NECA Tariff No. 4.
Cost of the Work The sum of all allowable costs necessarily incurred and paid by Contractor in the proper performance of the Work.
Treatment of Unallowable Costs Previously Submitted for Payment Mallinckrodt further agrees that within 120 days of the Effective Date of this Agreement it shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Mallinckrodt or any of its subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Mallinckrodt agrees that the United States, at a minimum, shall be entitled to recoup from Mallinckrodt any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Mallinckrodt or any of its subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Mallinckrodt or any of its subsidiaries or affiliates’ cost reports, cost statements, or information reports.
The Performance Improvement Process (a) The Performance Improvement Process will focus on the risks of non- performance and problem-solving. It may include one or more of the following actions:
(1) a requirement that the HSP develop and implement an improvement plan that is acceptable to the LHIN;
(2) the conduct of a Review;
(3) a revision and amendment of the HSP’s obligations; and
(4) an in-year, or year end, adjustment to the Funding, among other possible means of responding to the Performance Factor or improving performance.
(b) Any performance improvement process begun under a prior service accountability agreement that was not completed under the prior agreement will continue under this Agreement. Any performance improvement required by a LHIN under a prior service accountability agreement will be deemed to be a requirement of this Agreement until fulfilled or waived by the LHIN.
Completion of Services (a) The Customer must:
(i) notify Deswik in writing as soon as the Customer becomes aware of any defects in the Services; or
(ii) provide Deswik with an email confirming successful completion of any Services Deswik advises the Customer have been completed.
(b) If the Customer does not notify Deswik of any defects under clause 5.4(a)(i) or provide Deswik with an email confirming successful completion of the Services within 14 days of Deswik notifying the Customer that the relevant Services are complete, the Customer is deemed to have accepted the Services.
(c) If the Customer notifies Deswik of any defects under clause 5.4(a)(i), Deswik will, as soon as possible investigate and (where applicable) undertake rectification of the defects. Upon completion of any defect rectification the Customer must promptly provide an email notification of the successful completion of the services, unless further defects exist. In this case, the Customer is further required to notify Deswik of such defects.
Future Treatment of Unallowable Costs Unallowable Costs shall be separately determined and accounted for by Defendants, and Defendants shall not charge such Unallowable Costs directly or indirectly to any contracts with the United States or any State Medicaid program, or seek payment for such Unallowable Costs through any cost report, cost statement, information statement, or payment request submitted by Defendants or any of their subsidiaries or affiliates to the Medicare, Medicaid, TRICARE, or FEHBP Programs.
