Cost of Labour Relations Meetings The parties agree that efforts will be made to minimize costs related to the committee. C8.00 CUPE/SCFP MEMBERS ON PROVINCIAL COMMITTEES CUPE/SCFP appointees to Provincial Committees will not have their participation charged against local collective agreement union release time or days.
Selection of Labor During the performance of this contract, the contractor shall not use convict labor for any purpose within the limits of a construction project on a Federal-aid highway unless it is labor performed by convicts who are on parole, supervised release, or probation. The term Federal-aid highway does not include roadways functionally classified as local roads or rural minor collectors.
Criteria for Selection a. The Sabbatical Selection Committee shall use four (4) criteria for selection of academic employees to receive sabbaticals. These are: the merit of the sabbatical project, the applicant’s current and previous contributions to the College community, the proposal’s relevancy to the College’s Strategic Plan and whether or not the applicant has had a previous sabbatical. In instances where these criteria are equal, seniority shall be the determining factor.
NATIONAL LABOR RELATIONS BOARD CERTIFICATION Contractor certifies that no more than one (1) final unappealable finding of contempt of court by a Federal court has been issued against Contractor within the immediately preceding two-year period because of Contractor's failure to comply with an order of a Federal court, which orders Contractor to comply with an order of the National Labor Relations Board. (Pub. Contract Code §10296) (Not applicable to public entities.)
NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
NOTICE TO BUYER OF LABOR DISPUTES Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
Payment for Labor and Materials The Contractor agrees and binds itself to pay for all labor done, and for all the materials used in the construction of the work to be completed pursuant to this contract.
Time Off for Selection Procedures A regular, limited-term or probationary employee shall be entitled to necessary time off with pay to participate in tests of fitness, examinations and interviews required by the Chief Human Resources Officer during working hours for the purpose of determining eligibility for movement to another class in the County service or transfer from one agency/department to another.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of:
