Labour Laws (a) The Contractor shall obtain all relevant labour registrations and comply with all relevant labour laws applying to its employees, and shall duly pay them and afford to them all their legal rights.
(b) The Contractor shall make all deductions of tax at source and all contributions to the Payment of Gratuity, Provident Fund (including Employees’ contribution) and Employees’ State Insurance Scheme as may be required by Applicable Laws and deposit the aforesaid contributed amount with the appropriate authority/(s).
(c) The Contractor shall require all personnel engaged in the Works to obey all Applicable Laws and regulations. The Contractor shall permit Authority to witness labour payments for the Contractors direct labour, or the Subcontractors labour. The Contractor shall ensure that all its Subcontractors strictly comply with all labour laws.
(d) Documentary evidence confirming compliance with Sub-Clause 12.4, as may be required from time to time, shall be provided to the Employer’s Representative.
(e) The Employer shall not be liable for any delay/default of the Contractor in compliance of the labour laws.
Litigation; Labor Matters; Compliance with Laws (i) There is no suit, action or proceeding or investigation pending or, to the knowledge of the Company, threatened against or affecting the Company or any basis for any such suit, action, proceeding or investigation that, individually or in the aggregate, could reasonably be expected to have a material adverse effect with respect to the Company or prevent, hinder or materially delay the ability of the Company to consummate the transactions contemplated by this Agreement, nor is there any judgment, decree, injunction, rule or order of any Governmental Entity or arbitrator outstanding against the Company having, or which, insofar as reasonably could be foreseen by the Company, in the future could have, any such effect.
(ii) The Company is not a party to, or bound by, any collective bargaining agreement, contract or other agreement or understanding with a labor union or labor organization, nor is it the subject of any proceeding asserting that it has committed an unfair labor practice or seeking to compel it to bargain with any labor organization as to wages or conditions of employment nor is there any strike, work stoppage or other labor dispute involving it pending or, to its knowledge, threatened, any of which could have a material adverse effect with respect to Company.
(iii) The conduct of the business of the Company complies with all statutes, laws, regulations, ordinances, rules, judgments, orders, decrees or arbitration awards applicable thereto.
Compliance with Labor Laws Except as would not, individually or in the aggregate, result in a Material Adverse Change, (i) there is (A) no unfair labor practice complaint pending or, to the best of the Company’s knowledge, threatened against the Company or any of its subsidiaries before the National Labor Relations Board, and no grievance or arbitration proceeding arising out of or under collective bargaining agreements pending, or to the best of the Company’s knowledge, threatened, against the Company or any of its subsidiaries, (B) no strike, labor dispute, slowdown or stoppage pending or, to the best of the Company’s knowledge, threatened against the Company or any of its subsidiaries and (C) no union representation question existing with respect to the employees of the Company or any of its subsidiaries and, to the best of the Company’s knowledge, no union organizing activities taking place and (ii) there has been no violation of any federal, state or local law relating to discrimination in hiring, promotion or pay of employees or of any applicable wage or hour laws.
Unfair Labor Practices The Grantee shall comply with the Employers Engaging in Unfair Labor Practices Act, 1980 PA 278, as amended, MCL 423.321 et seq.
Third-Party Information; Privacy or Data Protection Laws Each Party acknowledges that it and its respective Subsidiaries may presently have and, after the Effective Time, may gain access to or possession of confidential or proprietary Information of, or personal Information relating to, Third Parties: (i) that was received under confidentiality or non-disclosure agreements entered into between such Third Parties, on the one hand, and the other Party or the other Party’s Subsidiaries, on the other hand, prior to the Effective Time or (ii) that, as between the two parties, was originally collected by the other Party or the other Party’s Subsidiaries and that may be subject to and protected by privacy, data protection or other applicable Laws. Each Party agrees that it shall hold, protect and use, and shall cause its Subsidiaries and its and their respective Representatives to hold, protect and use, in strict confidence the confidential and proprietary Information of, or personal Information relating to, Third Parties in accordance with privacy, data protection or other applicable Laws and the terms of any agreements that were either entered into before the Effective Time or affirmative commitments or representations that were made before the Effective Time by, between or among the other Party or the other Party’s Subsidiaries, on the one hand, and such Third Parties, on the other hand.
Convicted, Discriminatory, Antitrust Violator, and Suspended Vendor Lists In accordance with sections 287.133, 287.134, and 287.137, F.S., the Contractor is hereby informed of the provisions of sections 287.133(2)(a), 287.134(2)(a), and 287.137(2)(a), F.S. For purposes of this Contract, a person or affiliate who is on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List may not perform work as a contractor, supplier, subcontractor, or consultant under the Contract. The Contractor must notify the Department if it or any of its suppliers, subcontractors, or consultants have been placed on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List during the term of the Contract. In accordance with section 287.1351, F.S., a vendor placed on the Suspended Vendor List may not enter into or renew a contract to provide any goods or services to an agency after its placement on the Suspended Vendor List. A firm or individual placed on the Suspended Vendor List pursuant to section 287.1351, F.S., the Convicted Vendor List pursuant to section 287.133, F.S., the Antitrust Violator Vendor List pursuant to section 287.137, F.S., or the Discriminatory Vendor List pursuant to section 287.134, F.S., is immediately disqualified from Contract eligibility.
Sanctions Concerns and Anti Corruption Laws (a) No Loan Party, nor any Subsidiary, nor, to the knowledge of the Loan Parties, any director, officer, employee, agent, affiliate or representative thereof, is an individual or entity that is, or is owned or controlled by any individual or entity that is (i) currently the subject or target of any Sanctions, (ii) included on OFAC’s List of Specially Designated Nationals, HMT’s Consolidated List of Financial Sanctions Targets and the Investment Ban List, or any similar list enforced by any other relevant sanctions authority or (iii) located, organized or resident in a Designated Jurisdiction.
(b) The Loan Parties and their Subsidiaries have conducted their business in compliance with the United States Foreign Corrupt Practices Act of 1977, the UK Bxxxxxx Xxx 0000 and other similar anti-corruption legislation in other jurisdictions, and have instituted and maintained policies and procedures designed to promote and achieve compliance with such laws and applicable Sanctions, and to the knowledge of the Borrower, the Loan Parties and their Subsidiaries are in compliance with such anti-corruption laws and applicable Sanctions in all material respects.
Anti-Corruption Laws and Sanctions The Borrower has implemented and maintains in effect policies and procedures designed to ensure compliance by the Borrower, its Subsidiaries and their respective directors, officers, employees and agents with Anti-Corruption Laws and applicable Sanctions, and the Borrower, its Subsidiaries and their respective officers and employees and to the knowledge of the Borrower its directors and agents, are in compliance with Anti-Corruption Laws and applicable Sanctions in all material respects. None of (a) the Borrower, any Subsidiary or any of their respective directors, officers or employees, or (b) to the knowledge of the Borrower, any agent of the Borrower or any Subsidiary that will act in any capacity in connection with or benefit from the credit facility established hereby, is a Sanctioned Person. No Borrowing or Letter of Credit, use of proceeds or other transaction contemplated by this Agreement will violate any Anti-Corruption Law or applicable Sanctions.
XxxXxxxx Principles - Northern Ireland The provisions of San Francisco Administrative Code §12F are incorporated herein by this reference and made part of this Agreement. By signing this Agreement, Contractor confirms that Contractor has read and understood that the City urges companies doing business in Northern Ireland to resolve employment inequities and to abide by the XxxXxxxx Principles, and urges San Francisco companies to do business with corporations that abide by the XxxXxxxx Principles.
CFR PART 200 Procurement of Recovered Materials A non-Federal entity that is a state agency or agency of a political subdivision of a state and its contractors must comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act. The requirements of Section 6002 include procuring only items designated in guidelines of the Environmental Protection Agency (EPA) at 40 CFR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. Does vendor certify that it is in compliance with the Solid Waste Disposal Act as described above? Yes