Notice to Proceed Contractor shall not, and shall not be obligated to, commence performance of the Work (other than the LNTP Work) until Owner issues the full notice to proceed (“Notice to Proceed” or “NTP”) authorizing the same pursuant to the terms and conditions of this Agreement. Upon Contractor’s receipt from Owner of the NTP, Contractor shall promptly commence with the performance of the Work. The NTP shall be issued in the form attached hereto as Attachment H, Schedule H-2. Contractor shall timely file in the required superior court and post at the Site a notice of commencement as required under La. Rev. Stat. §9:4801, et. seq. and shall provide copies of such notice of commencement to Subcontractors and Sub-subcontractors as required under La. Rev. Stat. §9:4801, et. seq. Owner shall not issue an NTP until the following conditions have been met:
Right to Proceed The Sponsor acknowledges the rights of Holders to institute a Direct Action as set forth in Section 2.8(d) hereto.
Fund's Right to Proceed Notwithstanding anything to the contrary contained herein, each Fund shall have, at its election upon reasonable notice to the Custodian, the right to enforce, to the extent permitted by any applicable agreement and applicable law, the Custodian's rights against any Subcustodian, Securities System, Eligible Securities Depository or other Person for loss, damage or expense caused such Fund by such Subcustodian, Securities System, Eligible Securities Depository or other Person, and shall be entitled to enforce the rights of the Custodian with respect to any claim against such Subcustodian, Securities System, Eligible Securities Depository or other Person, which the Custodian may have as a consequence of any such loss, damage or expense, if and to the extent that such Fund has not been made whole for any such loss or damage. If the Custodian makes such Fund whole for any such loss or damage, the Custodian shall retain the ability to enforce its rights directly against such Subcustodian, Securities System, Eligible Securities Depository or other Person. Upon such Fund's election to enforce any rights of the Custodian under this Section 5.05, such Fund shall reasonably prosecute all actions and proceedings directly relating to the rights of the Custodian in respect of the loss, damage or expense incurred by such Fund; provided that, so long as such Fund has acknowledged in writing its obligation to indemnify the Custodian under Section 5.03 hereof with respect to such claim, such Fund shall retain the right to settle, compromise and/or terminate any action or proceeding in respect of the loss, damage or expense incurred by such Fund without the Custodian's consent and provided further, that if such Fund has not made an acknowledgment of its obligation to indemnify, such Fund shall not settle, compromise or terminate any such action or proceeding without the written consent of the Custodian, which consent shall not be unreasonably withheld or delayed. The Custodian agrees to cooperate with each Fund and take all actions reasonably requested by such Fund in connection with such Fund's enforcement of any rights of the Custodian. Each Fund agrees to reimburse the Custodian for all reasonable out-of-pocket expenses incurred by the Custodian on behalf of such Fund in connection with the fulfillment of its obligations under this Section 5.05; provided, however, that such reimbursement shall not apply to expenses occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian.
Fund to Provide Documents Upon request, the Fund will provide to Insurer one complete copy of SEC registration statements, Fund Prospectuses, reports, any preliminary and final proxy material, applications for exemptions, requests for no-action letters, and all amendments to any of the above, that relate to the Fund or its shares, contemporaneously with the filing of such document with the SEC or other regulatory authorities.
Company Right to Prosecute So long as Company remains the only licensee of the Patent Rights and Biological Materials in the Field, Company shall have the right, under its own control and at its own expense, to prosecute any third party infringement of the Patent Rights in the Field or, together with licensees of the Patent Rights in other fields (if any), to defend the Patent Rights in any declaratory judgment action brought by a third party which alleges invalidity, unenforceability, or non-infringement of the Patent Rights. Prior to commencing any such action, Company shall consult with Medical School and shall consider the views of Medical School regarding the advisability of the proposed action and its effect on the public interest. Company shall not enter into any settlement, consent judgment, or other voluntary final disposition of any infringement action under this Subsection without the prior written consent of Medical School, which consent shall not be unreasonably withheld or delayed. Any recovery obtained in an action under this Subsection shall be distributed as follows: (i) each party shall be reimbursed for any expenses incurred in the action (including the amount of any royalty payments withheld from Medical School as described below), (ii) as to ordinary damages, Company shall receive an amount equal to its lost profits or a reasonable royalty on the infringing sales (whichever measure of damages the court shall have applied), less a reasonable approximation of the royalties that Company would have paid to Medical School if Company had sold the infringing products and services rather than the infringer, and (iii) as to special or punitive damages, the parties shall share equally in any award. Company may offset a total of fifty percent (50%) of any expenses incurred under this Subsection against any royalty payments due to Medical School under this Agreement, provided that in no event shall the royalty payments under Section 4.5. and 4.7., when aggregated with any other offsets and credits allowed under this Agreement, be reduced by more than fifty percent (50%) in any Royalty Period.
Failure to Provide Insurance Lessee acknowledges that any failure on its part to obtain or maintain the insurance required herein will expose Lessor to risks and potentially cause Lessor to incur costs not contemplated by this Lease, the extent of which will be extremely difficult to ascertain. Accordingly, for any month or portion thereof that Lessee does not maintain the required insurance and/or does not provide Lessor with the required binders or certificates evidencing the existence of the required insurance, the Base Rent shall be automatically increased, without any requirement for notice to Lessee, by an amount equal to 10% of the then existing Base Rent or $100, whichever is greater. The parties agree that such increase in Base Rent represents fair and reasonable compensation for the additional risk/costs that Lessor will incur by reason of Lessee’s failure to maintain the required insurance. Such increase in Base Rent shall in no event constitute a waiver of Lessee’s Default or Breach with respect to the failure to maintain such insurance, prevent the exercise of any of the other rights and remedies granted hereunder, nor relieve Lessee of its obligation to maintain the insurance specified in this Lease.
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Development of the Project The Board of Managers shall take such actions as shall be required to cause either the Company or the Management Company (as defined in Section 9(b) below) to perform and complete the construction and other development work as contemplated and/or required under the NVR Purchase and Sale Agreements, or any other construction company selected by the Board of Managers (the “Development Work”), substantially in accordance with the Project Plan, at a cost to the Company not exceeding the total cost set forth in the Budget, in a manner consistent with this Agreement and all applicable laws, ordinances, rules, regulations or requirements (including, without limitation, those with respect to discrimination) of governmental authorities, and in compliance with any covenants, conditions or restrictions affecting all or any portion of the Property.
Completion of the Project (a) The completion of the Project shall be evidenced to the Trustee by a certificate signed by the Project Supervisor on behalf of the User stating that (1) construction of the Improvements has been completed in accordance with the plans and specifications approved by the User, (2) the Equipment has been acquired and installed in accordance with the User's instructions, (3) all Project Costs have been paid, and (4) all facilities and improvements necessary in connection with the Project have been acquired and installed and all costs and expenses incurred in connection therewith have been paid. Notwithstanding the foregoing, such certificate shall state that it is given without prejudice to any rights against any vendor, contractor, subcontractor or other person not a party to this Lease Agreement which exist at the date of such certificate or which may subsequently come into being. The Issuer and the User will cooperate in causing such certificate to be furnished to the Trustee.
