Deemed Termination upon Sample Clauses

Deemed Termination upon delay Without prejudice to the provisions of Clauses 8.3, and subject to the provisions of Clause 7.3, the Parties expressly agree that in the event the Appointed Date does not occur, for any reason whatsoever, within 90 days of signing of the Agreement and submission of the full Performance Security by the Contractor, the Agreement shall be deemed to have been terminated. The Authority shall pay damages to the Contractor equivalent to 1% of the Contract Price (3% in case of standalone bridge projects). All other rights, privileges, claims and entitlements of the Contractor under or arising out of this Agreement shall be deemed to have been waived by, and to have ceased. The Contractor shall hand over all information in relation to the Highway, including but not limited to any data, designs, drawings, structures, information, plans, etc. prepared by them for the Highway, to the Authority. 9 Clause 3.3 may be suitably modified in the event that all the environmental clearances for the Project Highway have been received or are not required. It should be clearly stated that all the environmental clearances for the Project Highway have been received; or such environmental clearances for the Project Highway are not required. Draft Contract AgreementPage 33 of 145 Nov 2020 Article 4 Obligations of the Contractor 4.1 Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfill, comply with and perform all its obligations set out in this Agreement or arising hereunder.
Sample 1See All (7)
AutoNDA by SimpleDocs
Deemed Termination upon delay Without prejudice to the provisions of Clauses 8.3, and subject to the provisions of Clause 7.3, the Parties expressly agree that in the event the Appointed Date does not occur, for any reason whatsoever, within 90 days of signing of the Agreement and submission of the full Performance Security by the Contractor, the Agreement shall be deemed to have been terminated. The Authority shall pay damages to the Contractor equivalent to 1% of the Contract Price (3% in case of standalone bridge projects). All other rights, privileges, claims and entitlements of the Contractor under or arising out of this Agreement shall be deemed to have been waived by, and to have ceased. The Contractor shall hand over all information in relation to the Highway, including but not limited to any data, designs, drawings, structures, information, plans, etc. prepared by them for the Highway, to the Authority. 9 Clause 3.3 may be suitably modified in the event that all the environmental clearances for the Project Highway have been received or are not required. It should be clearly stated that all the Contract AgreementPage 33 of 157 Widening & Upgradation to 2-lane with paved shoulder from km 39.450 (start of Pahalgam Bypass) to km 60.680 (Chandanwadi), Package-III of Khanabal - Pahalgam - Chandanwadi - Baltal section of NH-501 in the UT of Jammu & Kashmir on EPC Mode January’ 2024 environmental clearances for the Project Highway have been received; or such environmental clearances for the Project Highways are not required. Contract AgreementPage 34 of 157 Widening & Upgradation to 2-lane with paved shoulder from km 39.450 (start of Pahalgam Bypass) to km 60.680 (Chandanwadi), Package-III of Khanabal - Pahalgam - Chandanwadi - Baltal section of NH-501 in the UT of Jammu & Kashmir on EPC Mode January’ 2024 Article 4 Obligations of the Contractor 4.1
Sample 1See All (6)

Related to Deemed Termination upon

  • Deemed Termination upon delay Without prejudice to the provisions of Clauses 8.3, and subject to the provisions of Clause 7.3, the Parties expressly agree that in the event the Appointed Date does not occur, for any reason whatsoever, within 90 days of signing of the Agreement and submission of the full Performance Security by the Contractor, the Agreement shall be deemed to have been terminated. The Authority shall pay damages to the Contractor equivalent to 1% of the Contract Price (3% in case of standalone bridge projects). All other rights, privileges, claims and entitlements of the Contractor under or arising out of this Agreement shall be deemed to have been waived by, and to have ceased. The Contractor shall hand over all information in relation to the Highway, including but not limited to any data, designs, drawings, structures, information, plans, etc. prepared by them for the Highway, to the Authority. 9 Clause 3.3 may be suitably modified in the event that all the environmental clearances for the Project Highway have been received or are not required. It should be clearly stated that all the environmental clearances for the Project Highway have been received; or such environmental clearances for the Project Highway are not required.

  • Deemed Termination A full-time or regular part-time nurse shall lose all service and seniority and shall be deemed to have terminated if the nurse: (a) leaves of her or his own accord; (b) is discharged and the discharge is not reversed through the grievance or arbitration procedure; (c) has been laid off for twenty-four (24) calendar months; (d) refuses to continue to work or return to work during an emergency which seriously affects the Hospital's ability to provide adequate patient care, unless a satisfactory reason is given to the Hospital; (e) is absent from scheduled work for a period of three (3) or more consecutive working days without notifying the Hospital of such absence and providing a satisfactory reason to the Hospital; (f) fails to return to work (subject to the provisions of 10.06 (e)) upon termination of an authorized leave of absence without satisfactory reason or utilizes a leave of absence for purposes other than that for which the leave was granted; (g) fails upon being notified of a recall to signify her or his intention to return within twenty (20) calendar days after she or he has received the notice of recall mailed by registered mail to the last known address according to the records of the Hospital and fails to report to work within thirty (30) calendar days after she or he has received the notice of recall or such further period of time as may be agreed upon by the parties;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!