Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Defense With respect to any Proceeding as to which Indemnitee notifies the Company of the commencement thereof, the Company will be entitled to participate in the Proceeding at its own expense and except as otherwise provided below, to the extent the Company so wishes, it may assume the defense thereof with counsel reasonably satisfactory to Indemnitee. After notice from the Company to Indemnitee of its election to assume the defense of any Proceeding, the Company shall not be liable to Indemnitee under this Agreement or otherwise for any Expenses subsequently incurred by Indemnitee in connection with the defense of such Proceeding other than reasonable costs of investigation or as otherwise provided below. Indemnitee shall have the right to employ legal counsel in such Proceeding, but all Expenses related thereto incurred after notice from the Company of its assumption of the defense shall be at Indemnitee’s expense unless: (i) the employment of legal counsel by Indemnitee has been authorized by the Company, (ii) Indemnitee has reasonably determined that there may be a conflict of interest between Indemnitee and the Company in the defense of the Proceeding, (iii) after a Change in Control (other than a Change in Control approved by a majority of the directors on the Board who were directors immediately prior to such Change in Control), the employment of counsel by Indemnitee has been approved by the Independent Counsel, or (iv) the Company shall not in fact have employed counsel to assume the defense of such Proceeding, in each of which cases all Expenses of the Proceeding shall be borne by the Company. The Company shall not be entitled to assume the defense of any Proceeding brought by or on behalf of the Company or as to which Indemnitee shall have made the determination provided for in (ii), (iii) and (iv) above.
Defendants “Defendants” means Xxxx X. XXXX, Acting Secretary of Homeland Security, in his official capacity; Xxxxxxx XXXX, Attorney General of the United States, in his official capacity; Xxxxxxx X. XXXXXXX, Deputy Director for ICE (Senior Official Performing the Duties of the Director, ICE), in his official capacity; Xxxxxxx X. XXXXXXXXXX, Senior Official Performing the Duties of the Director, USCIS, in his official capacity; Xxxx X. XXXXXX, Acting Commissioner of CBP, in his official capacity; and Xxxxx XXXXXXX, Director of EOIR, in his official capacity.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Defense of Claims Subject to the provisions of applicable policies of directors’ and officers’ liability insurance, if any, the Company shall be entitled to participate in the defense of any Indemnifiable Claim or to assume or lead the defense thereof with counsel reasonably satisfactory to the Indemnitee; provided that if Indemnitee determines, after consultation with counsel selected by Indemnitee, that (a) the use of counsel chosen by the Company to represent Indemnitee would present such counsel with an actual or potential conflict, (b) the named parties in any such Indemnifiable Claim (including any impleaded parties) include both the Company and Indemnitee and Indemnitee shall conclude that there may be one or more legal defenses available to him or her that are different from or in addition to those available to the Company, (c) any such representation by such counsel would be precluded under the applicable standards of professional conduct then prevailing, or (d) Indemnitee has interests in the claim or underlying subject matter that are different from or in addition to those of other Persons against whom the Claim has been made or might reasonably be expected to be made, then Indemnitee shall be entitled to retain separate counsel (but not more than one law firm plus, if applicable, local counsel in respect of any particular Indemnifiable Claim for all indemnitees in Indemnitee’s circumstances) at the Company’s expense. The Company shall not be liable to Indemnitee under this Agreement for any amounts paid in settlement of any threatened or pending Indemnifiable Claim effected without the Company’s prior written consent. The Company shall not, without the prior written consent of the Indemnitee, effect any settlement of any threatened or pending Indemnifiable Claim which the Indemnitee is or could have been a party unless such settlement solely involves the payment of money and includes a complete and unconditional release of the Indemnitee from all liability on any claims that are the subject matter of such Indemnifiable Claim. Neither the Company nor Indemnitee shall unreasonably withhold its consent to any proposed settlement; provided that Indemnitee may withhold consent to any settlement that does not provide a complete and unconditional release of Indemnitee.
Litigation and Claims No litigation, claim, investigation, administrative proceeding or similar action (including those for unpaid taxes) against Borrower is pending or threatened, and no other event has occurred which may materially adversely affect Borrower’s financial condition or properties, other than litigation, claims, or other events, if any, that have been disclosed to and acknowledged by Lender in writing.
Other Legal Actions The actions stipulated in this Integrity Pact are without prejudice to any other legal action that may follow in accordance with the provisions of the extant law in force relating to any civil or criminal proceedings.
Defendant shall make a good faith effort to issue a final decision on Xx. Xxxxx’x claim, if appropriate, as soon as practicable.
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
