DEFINITION OF THE BUYER’S DEFAULT Sample Clauses

DEFINITION OF THE BUYER’S DEFAULT. The BUYER shall be deemed to be in default under this CONTRACT in the following cases : (i) If the first, second, third, fourth or fifth instalment is not paid to the BUILDER within respective DUE DATE of such instalments as required by Article X; or (ii) If the sixth instalment is not deposited in accordance with Article X.4.(a)(ii) hereof or if the said sixth instalment deposit is not released to the BUILDER against presentation by the BUILDER of a duplicate original copy of the PROTOCOL OF DELIVERY AND ACCEPTANCE; or (iii) If the BUYER fails to take delivery of the VESSEL when the VESSEL is duly tendered for delivery by the BUILDER under the provisions of Article VII hereof; or (iv) If an order or an effective resolution shall be passed for winding up of the BUYER (except for the purpose of reorganization, merger or amalgamation).
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
DEFINITION OF THE BUYER’S DEFAULT. The BUYER shall be deemed to be in default of performance of its obligations under this Contract in the following cases: (a) If the BUYER fails to pay any of the First, Second, Third and Forth Instalments to the BUILDER after such Instalment becomes due and payable under the provision of Article II hereof; or (b) If the BUYER fails to pay the Fifth Instalment to the BUILDER concurrently with the delivery of the VESSEL by the BUILDER to the BUYER as provided in Article II hereof; or (c) If the BUYER fails to take delivery of the VESSEL, when the VESSEL is duly tendered for delivery by the BUILDER under the provisions of Article VII hereof. (d) If BUYER or guarantee company who issue Performance Guarantee in the form as per Annex B (hereinafter called “Guarantor”) becomes bankrupt or insolvent under any applicable laws, or if an administrator, receiver or similar officer is appointed for or in relation to BUYER or Guarantor or all or any of its assets, or if BUYER or Guarantor enters into any special arrangement or composition with its creditors with a view to restructuring its debts or liabilities, or if any moratorium is applied for or declared in respect of BUYER or Guarantor, or if BUYER or Guarantor seeks protection from any of its creditors; or if the BUYER or the Guarantor is dissolved, liquidated, rehabilitated or ceases to be registered as a company.
Sample 1Sample 2

Related to DEFINITION OF THE BUYER’S DEFAULT

  • Buyer’s Default Seller’s remedies shall be limited to liquidated damages in the amount of the Xxxxxxx Money set forth in Section IV. It is agreed that such payments and things of value are liquidated damages and are Seller’s sole and only remedy for Buyer’s failure to perform the obligations of this Agreement. The Parties agree that Seller’s actual damages in the event of Buyer’s default would be difficult to measure, and the amount of the liquidated damages herein provided for is a reasonable estimate of such damages.

  • Seller’s Default Buyer may elect to treat this Agreement as cancelled, in which case all Xxxxxxx Money paid by Buyer hereunder shall be returned and Buyer may recover such damages as may be proper, or Buyer may elect to treat this Agreement as being in full force and effect and Buyer shall have the right to specific performance or damages, or both.

  • Purchaser’s Default 12.1 If the Purchaser fails to pay, on due date any instalment or other moneys which the Purchaser may be required to pay, in terms hereof (provided that no notice need be given if the breach is the non-payment of the deposit in paragraph 4 of the Schedule of Particulars) or commits any other breach of any of the terms and conditions of this agreement (or of any of the rules and regulations to which the Purchaser is subject in respect of the Property or Building, including the Unit), the Seller shall be entitled without prejudice to any other remedies that it may have at law, if the Purchaser fails to remedy such breach, default or non- payment within 7 (seven) days of dispatch of written notice calling upon the Purchaser to do so: 12.1.1 to cancel this agreement, retake possession of the Unit and claim all damages suffered by reason of the Purchaser's breach of contract; or 12.1.2 to claim specific performance or immediate payment of the purchase price, interest and all other amounts as may be payable by the Purchaser in terms of this agreement. 12.2 If this agreement is cancelled as hereinbefore provided, the Purchaser and all persons claiming a right of occupation through the Purchaser, shall forthwith be obliged to vacate the Unit and to deliver it to the Seller. No lease or other right of occupation in favour of the Purchaser shall be created or come into existence by virtue of this agreement. 12.3 If the Purchaser disputes the Seller's right to cancel this agreement, then pending the determination of such dispute, the Purchaser shall be obliged to continue to pay all amounts payable by him in terms of this agreement on the due dates thereof and the Seller shall be entitled to accept such payments without prejudice to its rights of cancellation as aforesaid. If such dispute is decided in favour of the Seller then such amounts so received by the Seller after cancellation as aforesaid shall be deemed to have been paid to the Seller prior to cancellation. 12.4 Should this agreement be cancelled in terms of this clause the Purchaser shall not be entitled to claim or receive any compensation whatsoever from the Seller for any alterations, additions or improvements effected to or on the Unit save only as otherwise provided by law.

  • Buyer Default If Buyer defaults under this Contract after the Review Period, and such default continues for thirty (30) days following written notice from Seller (provided no notice shall extend the time for Closing), then at Seller’s election by written notice to Buyer, this Contract shall be terminated and of no effect, in which event the Xxxxxxx Money Deposit, including any interest thereon, shall be paid to and retained by the Seller as Seller’s sole and exclusive remedy hereunder, and as liquidated damages for Buyer’s default or failure to close, and both Buyer and Seller shall thereupon be released from all obligations hereunder.

  • Seller Default If a Seller, prior to the Closing, defaults in its representations, warranties, covenants, or obligations under this Agreement, including to sell its Property as required by this Agreement and such default continues for more than ten (10) days after written notice from Purchaser, then, at Purchaser’s election, Purchaser may either (i) if Purchaser has closed on the remaining Properties for which there has been no default alleged, seek specific performance of the defaulting Seller’s obligations pursuant to this Agreement (but not damages); or (ii) give a Termination Notice to Sellers’ Representative of Purchaser’s decision to terminate this Agreement for the Properties for which there was such a default, proceed to Closing on the remaining Properties, and the applicable Seller shall pay to Purchaser an amount equal to the Applicable Share of the Deposit for the terminated Properties, Return on Deposit on the Applicable Share amount (or credit the same to Purchaser against the Base Purchase Price for the other Properties for which this Agreement has not been terminated), an amount equal to the actual third party costs incurred by Purchaser relating to breaking Purchaser’s rate lock with respect to the terminated Properties (provided Sellers’ liability for such costs to Purchaser related to breaking the rate lock shall not exceed $2,000,000 in the aggregate regardless of the number of terminated Properties), and, if Sellers’ default under this Agreement resulted from an intentional action or inaction of Sellers taken in bad faith (excluding any action or inaction a Seller reasonably takes or refuses to take in response to a request or requirement of any Lender) that causes one (1) or more of the Closings not to occur solely as a result of such action or inaction, a termination fee of $8,000,000 (the “Termination Fee”) (provided Purchaser has otherwise performed it obligations under this Agreement with respect to the other remaining Properties, including delivery of the Purchase Price therefor, and Sellers have been afforded notice and an opportunity to cure as provided above but have failed to so cure). The amount of the Termination Fee that may be collected by Purchaser shall be limited to $8,000,000, regardless of the number of Sellers alleged to have defaulted hereunder. Purchaser shall be entitled to execute on the Guaranty for any of the Applicable Share of the Deposit, Return on Deposit, and Termination Fee if the same are not returned within one (1) day after termination of the Agreement with respect to the Property or Properties in question.

  • Purchaser Default If Purchaser defaults in its obligations hereunder to (a) deliver the Initial Deposit or Additional Deposit (or any other deposit or payment required of Purchaser hereunder), (b) deliver to the Seller the deliveries specified under Section 5.3 on the date required thereunder, or (c) deliver the Purchase Price at the time required by Section 2.2.3 and close on the purchase of the Property on the Closing Date, then, immediately and without the right to receive notice or to cure pursuant to Section 2.3.3, Purchaser shall forfeit the Deposit, and the Escrow Agent shall deliver the Deposit to Seller, and neither party shall be obligated to proceed with the purchase and sale of the Property. If, Purchaser defaults in any of its other representations, warranties or obligations under this Contract, and such default continues for more than 10 days after written notice from Seller, then Purchaser shall forfeit the Deposit, and the Escrow Agent shall deliver the Deposit to Seller, and neither party shall be obligated to proceed with the purchase and sale of the Property. The Deposit is liquidated damages and recourse to the Deposit is, except for Purchaser's indemnity and confidentiality obligations hereunder, Seller's sole and exclusive remedy for Purchaser's failure to perform its obligation to purchase the Property or breach of a representation or warranty. Seller expressly waives the remedies of specific performance and additional damages for such default by Purchaser. SELLER AND PURCHASER ACKNOWLEDGE THAT SELLER'S DAMAGES WOULD BE DIFFICULT TO DETERMINE, AND THAT THE DEPOSIT IS A REASONABLE ESTIMATE OF SELLER'S DAMAGES RESULTING FROM A DEFAULT BY PURCHASER IN ITS OBLIGATION TO PURCHASE THE PROPERTY. SELLER AND PURCHASER FURTHER AGREE THAT THIS SECTION 10.1 IS INTENDED TO AND DOES LIQUIDATE THE AMOUNT OF DAMAGES DUE SELLER, AND SHALL BE SELLER'S EXCLUSIVE REMEDY AGAINST PURCHASER, BOTH AT LAW AND IN EQUITY, ARISING FROM OR RELATED TO A BREACH BY PURCHASER OF ITS OBLIGATION TO CONSUMMATE THE TRANSACTIONS CONTEMPLATED BY THIS CONTRACT, OTHER THAN WITH RESPECT TO PURCHASER'S INDEMNITY AND CONFIDENTIALITY OBLIGATIONS HEREUNDER.

  • Termination and Default Either party, upon determination that the other party has failed or refused to perform or is otherwise in breach of any obligation or provision under this Agreement or the Contract Document, may give written notice of default to the defaulting party in the manner specified for the giving of notices herein. Termination of this Agreement by either party for any reason shall have no effect upon the rights or duties accruing to the parties prior to termination.

  • Frustration of Closing Conditions None of the Company, Parent or Sub may rely on the failure of any condition set forth in Section 6.01, 6.02 or 6.03, as the case may be, to be satisfied if such failure was caused by such party’s failure to act in good faith or to use its commercially reasonable efforts to consummate the Merger and the other transactions contemplated by this Agreement, as required by and subject to Section 5.03.

  • Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.

  • Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!