Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System.
4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System.
4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA.
4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code.
4.1.5 The Power Producer shall commission the Project within SCOD.
4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer.
4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.
PRESERVATION, MANAGEMENT AND MAINTENANCE OF MORTGAGED PROPERTY (a) Borrower shall not commit waste or permit impairment or deterioration of the Mortgaged Property.
(b) Borrower shall not abandon the Mortgaged Property.
(c) Borrower shall restore or repair promptly, in a good and workmanlike manner, any damaged part of the Mortgaged Property to the equivalent of its original condition, or such other condition as Lender may approve in writing, whether or not insurance proceeds or condemnation awards are available to cover any costs of such restoration or repair; however, Borrower shall not be obligated to perform such restoration or repair if (i) no Event of Default has occurred and is continuing, and (ii) Lender has elected to apply any available insurance proceeds and/or condemnation awards to the payment of Indebtedness pursuant to Section 19(h)(ii), (iii), (iv) or (v), or pursuant to Section 20.
(d) Borrower shall keep the Mortgaged Property in good repair, including the replacement of Personalty and Fixtures with items of equal or better function and quality.
(e) Borrower shall provide for professional management of the Mortgaged Property by a residential rental property manager satisfactory to Lender at all times under a contract approved by Lender in writing, which contract must be terminable upon not more than 30 days notice without the necessity of establishing cause and without payment of a penalty or termination fee by Borrower or its successors.
(f) Borrower shall give Notice to Lender of and, unless otherwise directed in writing by Lender, shall appear in and defend any action or proceeding purporting to affect the Mortgaged Property, Lender's security or Lender's rights under this Instrument. Borrower shall not (and shall not permit any tenant or other person to) remove, demolish or alter the Mortgaged Property or any part of the Mortgaged Property, including any removal, demolition or alteration occurring in connection with a rehabilitation of all or part of the Mortgaged Property, except (i) in connection with the replacement of tangible Personalty, (ii) if Borrower is a cooperative housing corporation or association, to the extent permitted with respect to individual dwelling units under the form of proprietary lease or occupancy agreement and (iii) repairs and replacements in connection with making an individual unit ready for a new occupant.
(g) Unless otherwise waived by Lender in writing, Borrower must have or must establish and must adhere to the MMP. If the Borrower is required to have an MMP, the Borrower must keep all MMP documentation at the Mortgaged Property or at the management agent's office and available for the Lender or the Loan Servicer to review during any annual assessment or other inspection of the Mortgaged Property that is required by Lender.
(h) If Borrower is a housing cooperative corporation or association, until the Indebtedness is paid in full Borrower shall not reduce the maintenance fees, charges or assessments payable by shareholders or residents under proprietary leases or occupancy agreements below a level which is sufficient to pay all expenses of the Borrower, including, without limitation, all operating and other expenses for the Mortgaged Property and all payments due pursuant to the terms of the Note and any Loan Documents.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Development Responsibilities From and after the Effective Date, BMS shall assume sole responsibility for the Development of Compounds and Products in the Field in the Territory during the Term at its own cost and expense (including responsibility for all funding, resourcing and decision-making, subject to Sections 3.3 and 3.4), except with respect to the performance by Ambrx of the Research Program activities assigned to Ambrx pursuant to the Research Plan and as otherwise may be agreed upon by the Parties in writing. BMS, by itself or through its Affiliates and Sublicensees, shall use Diligent Efforts to Develop a Compound or Product in the Field in accordance with the Development Plan for the purpose of obtaining a Regulatory Approval in each Major Market [***]. For clarity, it is understood and acknowledged that Diligent Efforts in the Development of Compounds and Products may include sequential implementation of Clinical Trials and/or intervals between Clinical Trials for data interpretation and clinical program planning and approval.
Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following:
A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. Projects must be authorized by the State prior to advertising for construction.
B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract.
C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting.
D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor.
E. If the Local Government is the responsible party, the State must review and approve change orders.
F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas.
G. Upon completion of the Project, the party constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Management Responsibilities The exclusive representative recognizes the right and obligation of the School Board to efficiently manage and conduct the operation of the School District within its legal limitations and with its primary obligation to provide educational opportunity for the students of the School District.
Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.
Operating Plan To Agent and Lenders, as soon as available, but not later than thirty (30) days after the end of each Fiscal Year, an annual combined operating plan (the "Operating Plan") for Parent and its Subsidiaries, approved by the Board of Directors of Parent, for the following Fiscal Year, which (i) includes a statement of all of the material assumptions on which such plan is based, (ii) includes projected monthly income statement, balance sheets and source and use of funds for the following year and (iii) Borrowing Availability projections, all prepared on the same basis and in similar detail as that on which operating results are reported (and in the case of cash flow projections, representing management's good faith estimates of future financial performance based on historical performance), and including plans for personnel, Capital Expenditures and facilities.