Common use of DELIVERIES OR PERFORMANCE Clause in Contracts

DELIVERIES OR PERFORMANCE. F.1. 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx to see the links to the FAR. You may also use a network ―search engine‖ (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work (APR 1984)

DELIVERIES OR PERFORMANCE. F.1. F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html xxxx://xxx.xxxxx.xxx/far or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx xxxx://xxx.xxxxxxxx.xxx/home.htm to see the links to the FAR. You may also use a network ―search engine‖ “search engine” (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work (APR 1984)

DELIVERIES OR PERFORMANCE. F.1. F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use a network ―search engine‖ “search engine” (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (STOP-WORK ORDER AUG 1989) 1989 52.242-17 Government Delay of Work (GOVERNMENT DELAY OF WORK APR 1984 52.242-14 SUSPENSION OF WORK APR 1984)

DELIVERIES OR PERFORMANCE. F.1. 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx to see the links to the FAR. You may also use a network ―search engine‖ “search engine” (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work (APR 1984)

DELIVERIES OR PERFORMANCE. F.1. F.1 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this addressat: xxxx://xxxxxxxxxx.xxx/far/index.html xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use a network ―search engine‖ an Internet “search engine” (e.g.such as, Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.24252.242.14 SUSPENSION OF WORK APR 1984 F.2 52.211-15 Stop Work Order (AUG 1989) 52.242-17 Government Delay of Work 10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)) The Contractor shall be required to:

DELIVERIES OR PERFORMANCE. F.1. F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: xxxx://xxxxxxxxxx.xxx/far/index.html xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use a network ―search engine‖ (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 Stop Work Order (STOP-WORK ORDER AUG 1989) 1989 52.242-17 Government Delay of Work (GOVERNMENT DELAY OF WORK APR 1984 52.242-14 SUSPENSION OF WORK APR 1984)