DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Additional Wet Weather Procedure 14.15.1 Remaining On Site a) for more than an accumulated total of four hours of ordinary time in any one day; or b) after the meal break, as provided for in clause 17.1 of the Award, for more than an accumulated total of 50% of the normal afternoon work time; or c) during the final two hours of the normal work day for more than an accumulated total of one hour, the Enterprise will not be entitled to require the employees to remain on site beyond the expiration of any of the above circumstances.
SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO. 4.2 The Authority reserves the right (acting reasonably) to specify that the MI Report be submitted by the Supplier using an alternative communication to that specified in paragraph 4.1 above such as email. The Supplier agrees to comply with any such instructions provided they do not materially increase the burden on the Supplier.
Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.
PRICING OF After Hours Coefficient What is your after hours coefficient for the RS Means Price Book for work performed after normal working hours?
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
JOC - PRICING OF After Hours Coefficient What is your after hours coefficient for the RS Means Price Book for work performed after normal working hours? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
Calculation of Charges Contractor shall provide an invoice to the City on a monthly basis for goods delivered and/or Services completed in the immediate preceding month, unless a different schedule is set out in Appendix B, “Calculation of Charges.” Compensation shall be made for goods and/or Services identified in the invoice that the City, in his or her sole discretion, concludes has been satisfactorily performed. In no event shall the amount of this Agreement exceed [insert whole dollar amount in numbers and words -- no pennies and no “.00”]. The breakdown of charges associated with this Agreement appears in Appendix B, “Calculation of Charges.” A portion of payment may be withheld until conclusion of the Agreement if agreed to by both Parties as retainage, described in Appendix B. In no event shall City be liable for interest or late charges for any late payments. City will not honor minimum service order charges for any services covered by this Agreement.
