Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Vendor’s Resellers as Related to This Agreement
Changes in Equipment, Systems, Etc USBFS reserves the right to make changes from time to time, as it deems advisable, relating to its systems, programs, rules, operating schedules and equipment, so long as such changes do not adversely affect the services provided to the Trust under this Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.
General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,
(1) the Interconnection Customer shall engineer, procure equipment, and construct the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades (or portions thereof) using Good Utility Practice and using standards and specifications provided in advance by the Participating TO;
(2) The Interconnection Customer’s engineering, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades shall comply with all requirements of law to which the Participating TO would be subject in the engineering, procurement or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(3) the Participating TO shall review, and the Interconnection Customer shall obtain the Participating TO’s approval of, the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, which approval shall not be unreasonably withheld, and the CAISO may, at its option, review the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(4) prior to commencement of construction, the Interconnection Customer shall provide to the Participating TO, with a copy to the CAISO for informational purposes, a schedule for construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, and shall promptly respond to requests for information from the Participating TO;
(5) at any time during construction, the Participating TO shall have the right to gain unrestricted access to the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades and to conduct inspections of the same;
(6) at any time during construction, should any phase of the engineering, equipment procurement, or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades not meet the standards and specifications provided by the Participating TO, the Interconnection Customer shall be obligated to remedy deficiencies in that portion of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades;
(7) the Interconnection Customer shall indemnify the CAISO and Participating TO for claims arising from the Interconnection Customer's construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades under the terms and procedures applicable to Article 18.1
Reporting of Sales to TIPS by Vendor The Participation Fee that was published as part of the Solicitation and the fee published is the legally effective fee, along with any fee conditions stated in the Solicitation. Collection of the fees by TIPS is required under Texas Government Code §791.011 Et seq. Fees are due on all TIPS purchases reported by either Vendor or Member. Fees are due to TIPS upon payment by the Member to the Vendor, Reseller or Vendor Assigned Dealer. Vendor, Reseller or Vendor Assigned Dealer agrees that the participation fee is due to TIPS for all Agreement sales immediately upon receipt of payment including partial payment, from the Member Entity and must be paid to TIPS at least on a monthly basis, specifically within 31 calendar days of receipt of payment, if not more frequently, or as otherwise agreed by TIPS in writing and signed by an authorized signatory of TIPS. Thus, when an awarded Vendor, Reseller or Vendor Assigned Dealer receives any amount of payment, even partial payment, for a TIPS sale, the legally effective fee for that amount is immediately due to TIPS from the Vendor and fees due to TIPS should be paid at least on a monthly basis, specifically within 31 calendar days of receipt of payment, if not more frequently. Vendor is required to report all sales under the TIPS contract to TIPS. When a public entity initiates a purchase with a TIPS Awarded Vendor, if the Member inquires verbally or in writing whether the Vendor holds a TIPS Contract, it is the duty of the Vendor to verify whether or not the Member is seeking a TIPS purchase. Once verified, the Vendor must include the TIPS Contract number on any communications and related sales documents exchanged with the TIPS Member entity. To report sales, the Vendor must login to the TIPS Vendor Portal online at xxxxx://xxx.xxxx-xxx.xxx/vendors_form.cfm and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS. Failure to render the participation fee to TIPS shall constitute a breach of this agreement with our parent governmental entity, Texas Education Service Center Region 8, as established by the Texas legislature and shall be grounds for termination of this agreement and any other agreement held with TIPS and possible legal action. Any overpayment of participation fees to TIPS by a Vendor will be refunded to the Vendor within ninety (90) days of receipt of notification if TIPS receives written notification of the overpayment not later than the expiration of six (6) months from the date of overpayment and TIPS determines that the amount was not legally due to TIPS pursuant to this agreement and applicable law. It is the Vendor’s responsibility to identify which sales are TIPS Agreement sales and pay the correct participation fee due for TIPS Agreement sales. Any notification of overpayment received by TIPS after the expiration of six (6) months from the date of overpayment will be non-refundable. Region 8 ESC and TIPS reserve the right to extend the six (6) month deadline to notify if approved by the Region 8 ESC Board of Directors. TIPS reserves all rights under the law to collect the fees due. Please contact TIPS at xxxx@xxxx-xxx.xxx or call (000) 000-0000 if you have questions about paying fees.
Processing of Customer Personal Data 3.1 UKG will:
3.1.1 comply with all applicable Data Protection Laws in the Processing of Customer Personal Data; and
3.1.2 not Process Customer Personal Data other than for the purpose, and in accordance with, the relevant Customer’s instructions as documented in the Agreement and this DPA, unless Processing is required by the Data Protection Laws to which the relevant UKG Processor is subject, in which case UKG to the extent permitted by the Data Protection Laws, will inform Customer of that legal requirement before the Processing of that Customer Personal Data.
3.2 Customer hereby:
3.2.1 instructs UKG (and authorizes UKG to instruct each Subprocessor) to: (a) Process Customer Personal Data; and (b) in particular, transfer Customer Personal Data to any country or territory subject to the provisions of this DPA, in each case as reasonably necessary for the provision of the Services and consistent with the Agreement.
3.2.2 warrants and represents that it is and will at all relevant times remain duly and effectively authorized to give the instructions set out in Section 3.2.1 on behalf of each relevant Customer Affiliate; and
3.2.3 warrants and represents that it has all necessary rights in relation to the Customer Personal Data and/or has collected all necessary consents from Data Subjects to Process Customer Personal Data to the extent required by Applicable Law.
3.3 Schedule 1 to this DPA sets out certain information regarding UKG’s Processing of Customer Personal Data as required by Article 28(3) of the GDPR (and equivalent requirements of other Data Protection Laws).
Use of Subservicers and Subcontractors (a) The Master Servicer shall cause any Subservicer used by the Master Servicer (or by any Subservicer) for the benefit of the Depositor to comply with the provisions of Section 3.16 and this Article XI to the same extent as if such Subservicer were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person). The Master Servicer shall be responsible for obtaining from each Subservicer and delivering to the Depositor any servicer compliance statement required to be delivered by such Subservicer under Section 3.16, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 11.07 and any certification required to be delivered to the Certifying Person under Section 11.05 as and when required to be delivered. As a condition to the succession to any Subservicer as subservicer under this Agreement by any Person (i) into which such Subservicer may be merged or consolidated, or (ii) which may be appointed as a successor to any Subservicer, the Master Servicer shall provide to the Depositor, at least 15 calendar days prior to the effective date of such succession or appointment, (x) written notice to the Depositor of such succession or appointment and (y) in writing and in form and substance reasonably satisfactory to the Depositor, all information reasonably requested by the Depositor in order to comply with its reporting obligation under Item 6.02 of Form 8-K.
(b) It shall not be necessary for the Master Servicer, any Subservicer or the Trustee to seek the consent of the Depositor or any other party hereto to the utilization of any Subcontractor. The Master Servicer or the Trustee, as applicable, shall promptly upon request provide to the Depositor (or any designee of the Depositor, such as the Master Servicer or administrator) a written description (in form and substance satisfactory to the Depositor) of the role and function of each Subcontractor utilized by such Person (or in the case of the Master Servicer or any Subservicer), specifying (i) the identity of each such Subcontractor, (ii) which (if any) of such Subcontractors are "participating in the servicing function" within the meaning of Item 1122 of Regulation AB, and (iii) which elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be a Reporting Subcontractor, the Master Servicer or the Trustee, as applicable, shall cause any such Subcontractor used by such Person (or in the case of the Master Servicer or any Subservicer) for the benefit of the Depositor to comply with the provisions of Sections 11.07 and 11.09 of this Agreement to the same extent as if such Subcontractor were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person) or the Trustee, as applicable. The Master Servicer or the Trustee, as applicable, shall be responsible for obtaining from each Subcontractor and delivering to the Depositor and the Master Servicer, any assessment of compliance and attestation required to be delivered by such Subcontractor under Section 11.05 and Section 11.07, in each case as and when required to be delivered.
