Provisional Certificate 12.2.1 Subject to the provisions of Clause 12.2.5, upon completion of all Works forming part of the Project Highway, save and except the Works for which Time Extension has been granted under Clause 10.5, the Authority’s Engineer shall, at the request of the Contractor, issue a provisional certificate of completion substantially in the form set forth in Schedule-L (the “Provisional Certificate”) if the Tests for and in respect of the completed Works are successful. The Provisional Certificate shall have appended thereto a list of outstanding items of work (the “Punch List”) that need to be completed in accordance with the provisions of this Agreement. The Contractor undertakes to complete the minor outstanding items of works in respect of those Sections of the Project Highway for which the Provisional Certificate has been issued, within a period of 30 (thirty) days of the date of Provisional Certificate, and those parts of the Works in respect of which Time Extension has been granted, within the extended period thereof. For the avoidance of doubt, the Parties agree that the Punch List shall include all Works for which Time Extension has been granted and shall also include any minor outstanding items of work forming part of the completed Sections if such works do not materially affect the use of the completed Sections for their intended purpose. The Parties further agree that Provisional Certificate shall not be issued if the completed Works cannot be safely and reliably placed in service of the Users thereof.
12.2.2 Upon issue of Provisional Certificate, the provisions of Articles 14 and 17 shall apply to the completed parts of the Project Highway and the property and ownership of all such completed Works shall vest in the Authority.
12.2.3 If the Authority’s Engineer determines that the Project Highway or any completed part thereof does not conform to the provisions of this Agreement and cannot be safely and reliably placed in operation, it shall forthwith make a report in this behalf and send copies thereof to the Authority and the Contractor and withhold issuance of the Provisional Certificate until the Defects or deficiencies are rectified by the Contractor and Tests are successful in accordance with this Article 12.
12.2.4 Notwithstanding anything to the contrary contained in Clause 12.2.3, the Authority may, at any time after receiving a report from the Authority’s Engineer under that Xxxxxx, direct the Authority’s Engineer to issue a Provisional Certificate under Clause 12.2.1 and such direction shall be complied forthwith.
12.2.5 No Provisional Certificate shall be issued under the provisions of this Clause 12.2 until the Contractor has submitted valid claims for payment of at least 80% (eighty per cent) of the amount arrived at after reducing the lump sum price specified in Clause 19.1.1 by the amount attributable to works which have been withdrawn under the provisions of Clause 8.3.3. For the avoidance of doubt and by way of illustration, the Parties agree that if the Contract Price specified in Clause 19.1.1 is Rs. 105 cr. (Rs. one hundred and five crore) and the works withdrawn under Clause 8.3.3 have a value of Rs. 5 cr. (Rs. five crore), a Provisional Certificate shall not be issued until valid claims for payment of an amount of Rs. 80 cr. (Rs. eighty crore) have been submitted by the Contractor in accordance with the provisions of this Agreement. It is further agreed that all price adjustments made in pursuance of Clause 19.10 shall not be reckoned for computation of the claims for payments referred to in this Clause 12.2.5.
Additional Certificates The Company shall have furnished to the Agents such certificate or certificates, in addition to those specifically mentioned herein, as the Agents may have reasonably requested as to the accuracy and completeness at each Representation Date of any statement in the Registration Statement or the Prospectuses or any documents filed under the Exchange Act and Canadian Securities Laws and deemed to be incorporated by reference into the Prospectuses, as to the accuracy at such Representation Date of the representations and warranties of the Company herein, as to the performance by the Company of its obligations hereunder, or as to the fulfillment of the conditions concurrent and precedent to the obligations hereunder of the Agents.
Medical Certificate 🞏 Absent from Work (first date of absence) 🞏 Not absent from work but requires accommodations (Employee Name) The information supplied will be used in a confidential manner and may assist in creating a return to work plan. I hereby consent to the completion of this form by: (Treating Medical Practitioner’s Name) (Signature of Employee) (Date)
Collection of Certain Mortgage Loan Payments; Deposits to Custodial Account (a) The Master Servicer shall make reasonable efforts to collect all payments called for under the terms and provisions of the Mortgage Loans, and shall, to the extent such procedures shall be consistent with this Agreement and the terms and provisions of any related Primary Insurance Policy, follow such collection procedures as it would employ in its good faith business judgment and which are normal and usual in its general mortgage servicing activities. Consistent with the foregoing, the Master Servicer may in its discretion (i) waive any late payment charge or any prepayment charge or penalty interest in connection with the prepayment of a Mortgage Loan and (ii) extend the Due Date for payments due on a Mortgage Loan in accordance with the Program Guide; provided, however, that the Master Servicer shall first determine that any such waiver or extension will not impair the coverage of any related Primary Insurance Policy or materially adversely affect the lien of the related Mortgage. Notwithstanding anything in this Section to the contrary, the Master Servicer shall not enforce any prepayment charge to the extent that such enforcement would violate any applicable law. In the event of any such arrangement, the Master Servicer shall make timely advances on the related Mortgage Loan during the scheduled period in accordance with the amortization schedule of such Mortgage Loan without modification thereof by reason of such arrangements unless otherwise agreed to by the Holders of the Classes of Certificates affected thereby; provided, however, that no such extension shall be made if any such advance would be a Nonrecoverable Advance. Consistent with the terms of this Agreement, the Master Servicer may also waive, modify or vary any term of any Mortgage Loan or consent to the postponement of strict compliance with any such term or in any manner grant indulgence to any Mortgagor if in the Master Servicer's determination such waiver, modification, postponement or indulgence is not materially adverse to the interests of the Certificateholders (taking into account any estimated Realized Loss that might result absent such action); provided, however, that the Master Servicer may not modify materially or permit any Subservicer to modify any Mortgage Loan, including without limitation any modification that would change the Mortgage Rate, forgive the payment of any principal or interest (unless in connection with the liquidation of the related Mortgage Loan or except in connection with prepayments to the extent that such reamortization is not inconsistent with the terms of the Mortgage Loan), capitalize any amounts owing on the Mortgage Loan by adding such amount to the outstanding principal balance of the Mortgage Loan, or extend the final maturity date of such Mortgage Loan, unless such Mortgage Loan is in default or, in the judgment of the Master Servicer, such default is reasonably foreseeable; provided, further, that (1) no such modification shall reduce the interest rate on a Mortgage Loan below one-half of the Mortgage Rate as in effect on the Cut-off Date, but not less than the sum of the rates at which the Servicing Fee and the Subservicing Fee with respect to such Mortgage Loan accrues plus the rate at which the premium paid to the Certificate Insurer, if any, accrues, (2) the final maturity date for any Mortgage Loan shall not be extended beyond the Maturity Date, (3) the Stated Principal Balance of all Reportable Modified Mortgage Loans subject to Servicing Modifications (measured at the time of the Servicing Modification and after giving effect to any Servicing Modification) can be no more than five percent of the aggregate principal balance of the Mortgage Loans as of the Cut-off Date, unless such limit is increased from time to time with the consent of the Rating Agencies and the Certificate Insurer, if any. In addition, any amounts owing on a Mortgage Loan added to the outstanding principal balance of such Mortgage Loan must be fully amortized over the remaining term of such Mortgage Loan, and such amounts may be added to the outstanding principal balance of a Mortgage Loan only once during the life of such Mortgage Loan. Also, the addition of such amounts described in the preceding sentence shall be implemented in accordance with the Program Guide and may be implemented only by Subservicers that have been approved by the Master Servicer for such purpose. In connection with any Curtailment of a Mortgage Loan, the Master Servicer, to the extent not inconsistent with the terms of the Mortgage Note and local law and practice, may permit the Mortgage Loan to be reamortized such that the Monthly Payment is recalculated as an amount that will fully amortize the remaining Stated Principal Balance thereof by the original Maturity Date based on the original Mortgage Rate; provided, that such re-amortization shall not be permitted if it would constitute a reissuance of the Mortgage Loan for federal income tax purposes, except if such reissuance is described in Treasury Regulation Section 1.860G-2(b)(3).
(b) The Master Servicer shall establish and maintain a Custodial Account in which the Master Servicer shall deposit or cause to be deposited on a daily basis, except as otherwise specifically provided herein, the following payments and collections remitted by Subservicers or received by it in respect of the Mortgage Loans subsequent to the Cut-off Date (other than in respect of principal and interest on the Mortgage Loans due on or before the Cut-off Date):
(i) All payments on account of principal, including Principal Prepayments made by Mortgagors on the Mortgage Loans and the principal component of any Subservicer Advance or of any REO Proceeds received in connection with an REO Property for which an REO Disposition has occurred;
(ii) All payments on account of interest at the Adjusted Mortgage Rate on the Mortgage Loans, including Buydown Funds, if any, and the interest component of any Subservicer Advance or of any REO Proceeds received in connection with an REO Property for which an REO Disposition has occurred;
(iii) Insurance Proceeds, Subsequent Recoveries and Liquidation Proceeds (net of any related expenses of the Subservicer);
(iv) All proceeds of any Mortgage Loans purchased pursuant to Section 2.02, 2.03, 2.04 or 4.07 (including amounts received from Residential Funding pursuant to the last paragraph of Section 4 of the Assignment Agreement in respect of any liability, penalty or expense that resulted from a breach of the Compliance With Laws Representation and all amounts required to be deposited in connection with the substitution of a Qualified Substitute Mortgage Loan pursuant to Section 2.03 or 2.04;
(v) Any amounts required to be deposited pursuant to Section 3.07(c) or 3.21;
(vi) All amounts transferred from the Certificate Account to the Custodial Account in accordance with Section 4.02(a);
(vii) Any amounts realized by the Subservicer and received by the Master Servicer in respect of any Additional Collateral; and
(viii) Any amounts received by the Master Servicer in respect of Pledged Assets. The foregoing requirements for deposit in the Custodial Account shall be exclusive, it being understood and agreed that, without limiting the generality of the foregoing, payments on the Mortgage Loans which are not part of the Trust Fund (consisting of payments in respect of principal and interest on the Mortgage Loans due on or before the Cut-off Date) and payments or collections in the nature of prepayment charges or late payment charges or assumption fees may but need not be deposited by the Master Servicer in the Custodial Account. In the event any amount not required to be deposited in the Custodial Account is so deposited, the Master Servicer may at any time withdraw such amount from the Custodial Account, any provision herein to the contrary notwithstanding. The Custodial Account may contain funds that belong to one or more trust funds created for mortgage pass-through certificates of other series and may contain other funds respecting payments on mortgage loans belonging to the Master Servicer or serviced or master serviced by it on behalf of others. Notwithstanding such commingling of funds, the Master Servicer shall keep records that accurately reflect the funds on deposit in the Custodial Account that have been identified by it as being attributable to the Mortgage Loans. With respect to Insurance Proceeds, Liquidation Proceeds, REO Proceeds and the proceeds of the purchase of any Mortgage Loan pursuant to Sections 2.02, 2.03, 2.04 and 4.07 received in any calendar month, the Master Servicer may elect to treat such amounts as included in the Available Distribution Amount for the Distribution Date in the month of receipt, but is not obligated to do so. If the Master Servicer so elects, such amounts will be deemed to have been received (and any related Realized Loss shall be deemed to have occurred) on the last day of the month prior to the receipt thereof.
(c) The Master Servicer shall use its best efforts to cause the institution maintaining the Custodial Account to invest the funds in the Custodial Account attributable to the Mortgage Loans in Permitted Investments which shall mature not later than the Certificate Account Deposit Date next following the date of such investment (with the exception of the Amount Held for Future Distribution) and which shall not be sold or disposed of prior to their maturities. All income and gain realized from any such investment shall be for the benefit of the Master Servicer as additional servicing compensation and shall be subject to its withdrawal or order from time to time. The amount of any losses incurred in respect of any such investments attributable to the investment of amounts in respect of the Mortgage Loans shall be deposited in the Custodial Account by the Master Servicer out of its own funds immediately as realized without any right of reimbursement.
(d) The Master Servicer shall give notice to the Trustee and the Company of any change in the location of the Custodial Account and the location of the Certificate Account prior to the use thereof.
Central Certificate System Subject to such rules, regulations and orders as the Commission may adopt, the Trustees may direct the custodian to deposit all or any part of the securities owned by the Trust in a system for the central handling of securities established by a national securities exchange or a national securities association registered with the Commission under the Securities Exchange Act of 1934, or such other Person as may be permitted by the Commission, or otherwise in accordance with the 1940 Act, pursuant to which system all securities of any particular class of any issuer deposited within the system are treated as fungible and may be transferred or pledged by bookkeeping entry without physical delivery of such securities, provided that all such deposits shall be subject to withdrawal only upon the order of the Trust.
DEPOSIT OF FUND ASSETS WITH THE UNDERLYING TRANSFER AGENT Underlying Shares beneficially owned by the Fund, on behalf of a Portfolio, shall be deposited and/or maintained in an account or accounts maintained with an Underlying Transfer Agent and the Custodian’s only responsibilities with respect thereto shall be limited to the following:
1) Upon receipt of a confirmation or statement from an Underlying Transfer Agent that such Underlying Transfer Agent is holding or maintaining Underlying Shares in the name of the Custodian (or a nominee of the Custodian) for the benefit of a Portfolio, the Custodian shall identify by book-entry that such Underlying Shares are being held by it as custodian for the benefit of such Portfolio.
2) In respect of the purchase of Underlying Shares for the account of a Portfolio, upon receipt of Proper Instructions, the Custodian shall pay out monies of such Portfolio as so directed, and record such payment from the account of such Portfolio on the Custodian’s books and records.
3) In respect of the sale or redemption of Underlying Shares for the account of a Portfolio, upon receipt of Proper Instructions, the Custodian shall transfer such Underlying Shares as so directed, record such transfer from the account of such Portfolio on the Custodian’s books and records and, upon the Custodian’s receipt of the proceeds therefor, record such payment for the account of such Portfolio on the Custodian’s books and records. The Custodian shall not be liable to the Fund for any loss or damage to the Fund or any Portfolio resulting from the maintenance of Underlying Shares with an Underlying Transfer Agent except for losses resulting directly from the fraud, negligence or willful misconduct of the Custodian or any of its agents or of any of its or their employees.
Rule 144A Global Certificate to Regulation S Global Certificate If a holder of a beneficial interest in the Rule 144A Global Certificate deposited with the Certificate Registrar as custodian for the Depository wishes at any time following the Restricted Period to exchange its interest in such Rule 144A Global Certificate for an interest in the Regulation S Global Certificate of the same Class, or to transfer its interest in such Rule 144A Global Certificate to an institution that is required to take delivery thereof in the form of an interest in a Regulation S Global Certificate, such holder may, subject to the rules and procedures of the Depository, exchange, or cause the exchange of, such interest for an equivalent beneficial interest in such Regulation S Global Certificate. Upon receipt by the Certificate Registrar, as registrar, at its office designated in Section 5.11 of this Agreement, of (1) instructions given in accordance with the Depository’s procedures from a Depository Participant directing the Certificate Registrar to credit or cause to be credited a beneficial interest in the Regulation S Global Certificate in an amount equal to the beneficial interest in the Rule 144A Global Certificate to be exchanged, (2) a written order given in accordance with the Depository’s procedures containing information regarding the participant account of the Depository to be credited with such increase and (3) a certificate in the form of Exhibit F to this Agreement given by the holder of such beneficial interest, then the Certificate Registrar shall instruct the Depository to reduce, or cause to be reduced, the Certificate Balance of the Rule 144A Global Certificate and to increase, or cause to be increased, the Certificate Balance of the Regulation S Global Certificate by the aggregate Certificate Balance of the beneficial interest in the Rule 144A Global Certificate to be exchanged, to credit or cause to be credited to the account of the Person specified in such instructions a beneficial interest in the Regulation S Global Certificate equal to the reduction in the Certificate Balance of the Rule 144A Global Certificate, and to debit, or cause to be debited, from the account of the Person making such exchange or transfer the beneficial interest in the Rule 144A Global Certificate that is being exchanged or transferred.
Initial Certificate Ownership Since the formation of the Trust by the contribution by the Depositor pursuant to Section 2.5, the Depositor has been the sole Certificateholder.
Annual Certificate The Custodian shall have received the initial or annual certificate, as the case may be, required by Article 13 hereof; 6)
CUSTODIAN’S CERTIFICATE State Street Bank and Trust Company, as custodian for the Acquired Fund (the "Custodian"), shall deliver at the Closing a certificate of an authorized officer stating that: (a) the Acquired Fund's portfolio securities, cash, and any other assets have been delivered in proper form to the Acquiring Fund on the Closing Date; and (b) all necessary taxes including all applicable federal and state stock transfer stamps, if any, shall have been paid, or provision for payment shall have been made, in conjunction with the delivery of portfolio securities by the Acquired Fund.
