General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.
Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.
Project Description The Project Description may be changed from time to time by, or with the consent of, the Company provided that any such change shall also be filed with the Issuer and provided further that no change in the Project Description shall materially change the function of the Project Facilities unless the Trustee shall have received (i) an Engineer's certificate that such changes will not impair the significance or character of the Project Facilities as Pollution Control Facilities and (ii) an Opinion of Bond Counsel or ruling of the Internal Revenue Service to the effect that such amendment will not adversely affect the exclusion of interest on the Bonds from gross income for federal income tax purposes.
Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
Specific Shall Not Limit General; Construction No specific provision contained in this Note shall limit or modify any more general provision contained herein. This Note shall be deemed to be jointly drafted by the Company and the Holder and shall not be construed against any person as the drafter hereof.
Amendment of Schedules Each party hereto agrees that, with respect to the representations and warranties of such party contained in this Agreement, such party shall have the continuing obligation until 24 hours prior to the anticipated effectiveness of the Registration Statement to supplement or amend promptly the Schedules hereto with respect to any matter hereafter arising or discovered which, if existing or known at the date of this Agreement, would have been required to be set forth or described in the Schedules, provided however, that supplements and amendments to Schedules 5.10, 5.11, 5.14 and 5.15 shall only have to be delivered at the Closing Date, unless such Schedule is to be amended to reflect an event occurring other than in the ordinary course of business. Notwithstanding the foregoing sentence, no amendment or supplement to a Schedule prepared by the Company that constitutes or reflects an event or occurrence that would have a Material Adverse Effect may be made unless TCI and a majority of the Founding Companies other than the Company consent to such amendment or supplement; and provided further, that no amendment or supplement to a Schedule prepared by TCI or Newco that constitutes or reflects an event or occurrence that would have a Material Adverse Effect may be made unless a majority of the Founding Companies consent to such amendment or supplement. For all purposes of this Agreement, including without limitation for purposes of determining whether the conditions set forth in Sections 8.1 and 9.1 have been fulfilled, the Schedules hereto shall be deemed to be the Schedules as amended or supplemented pursuant to this Section 7.8. In the event that one of the Other Founding Companies seeks to amend or supplement a Schedule pursuant to Section 7.8 of one of the Other Agreements, and such amendment or supplement constitutes or reflects an event or occurrence that would have a Material Adverse Effect on such Other Founding Company, TCI shall give the Company notice promptly after it has knowledge thereof. If TCI and a majority of the Founding Companies (other than the Founding Company seeking to amend or supplement a Schedule) consent to such amendment or supplement, which consent shall have been deemed given by TCI or any Founding Company if no response is received within 24 hours following receipt of notice of such amendment or supplement (or sooner if required by the circumstances under which such consent is requested), but the Company does not give its consent, the Company may terminate this Agreement pursuant to Section 12.1(iv) hereof. In the event that the Company seeks to amend or supplement a Schedule pursuant to this Section 7.8, and TCI and a majority of the Other Founding Companies do not consent to such amendment or supplement, this Agreement shall be deemed terminated by mutual consent as set forth in Section 12.1(i) hereof. In the event that TCI or Newco seeks to amend or supplement a Schedule pursuant to this Section 7.8 and a majority of the Founding Companies do not consent to such amendment or supplement, this Agreement shall be deemed terminated by mutual consent as set forth in Section 12.1(i) hereof. No party to this Agreement shall be liable to any other party if this Agreement shall be terminated pursuant to the provisions of this Section 7.8. No amendment of or supplement to a Schedule shall be made later than 24 hours prior to the anticipated effectiveness of the Registration Statement.
Selection of Architect/Construction Drawings Tenant shall retain an architect/space planner reasonably and mutually agreed upon by Landlord and Tenant (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. The Contractor (as that term is defined in Section 4.1 of this Work Letter) shall provide design-build services from qualified, Landlord-approved mechanical, electrical and plumbing contractors for the preparation of plans and engineering working drawings related to the Improvements. Landlord hereby approves Gensler as the Architect if Tenant decides to select them. Tenant shall retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building, provided that Tenant shall retain the subcontractors designated in Schedule 2 attached hereto for the fire alarm design and programming work (the “Fire Alarm Subcontractor”) and for building management systems (the “BMS Subcontractor”). Landlord hereby approves Gensler as the Engineer if Tenant decides to select them. Should Tenant choose to prepare fully engineered drawings in lieu of the design-build approach described above, then Tenant shall retain the Engineers to prepare all plans and engineering working drawings relating to the mechanical, electrical and plumbing work of the Improvements. The plans and drawings to be prepared by Architect, the design-build contractors (unless Tenant selects the fully engineered drawings approach described above), the Fire Alarm Subcontractor, the BMS Subcontractor and the Engineers hereunder shall be known collectively as the “Construction Drawings.” Landlord hereby approves Gensler and Revel to be the Architect if Tenant selects them. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant’s waiver and indemnity set forth in the Lease, as amended, shall specifically apply to the Construction Drawings.
Severability; Construction Whenever possible, each provision of this Agreement shall be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Agreement shall be prohibited by or invalid under applicable law, such provision shall be ineffective only to the extent of such prohibition or invalidity, without invalidating the remainder of such provisions or the remaining provisions of this Agreement. The parties hereto have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises, this Agreement shall be construed as if drafted jointly by the parties hereto, and no presumption or burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any of the provisions of this Agreement.
Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
