Landlord’s Representative Landlord has designated Xxxx Xxxxxxx as its sole representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Tenant Work Letter.
Tenant’s Representative Tenant has designated Xxxxx Xxxxxx as its sole representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Landlord, shall have full authority and responsibility to act on behalf of the Tenant as required in this Tenant Work Letter.
Landlord’s Representations Tenant acknowledges that neither Landlord nor any of its agents made any representations or warranties respecting the Property, the Building or the Leased Premises, upon which Tenant relied in entering into the Lease, which are not expressly set forth in this Lease. Tenant further acknowledges that neither Landlord nor any of its agents made any representations as to (i) whether the Leased Premises may be used for Tenant's intended use under existing Law, or (ii) the suitability of the Leased Premises for the conduct of Tenant's business, or (iii) the exact square footage of the Leased Premises, and that Tenant relies solely upon its own investigations with respect to such matters. Tenant expressly waives any and all claims for damage by reason of any statement, representation, warranty, promise or other agreement of Landlord or Landlord's agent(s), if any, not contained in this Lease or in any Exhibit attached hereto.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Tenant’s Representations In addition to any other representation or warranty set forth herein and as an inducement to Landlord to enter into this Lease, Tenant hereby represents and warrants to Landlord as follows:
(a) Tenant is a [limited liability company] which is duly organized and validly existing and in good standing under the laws of the state of its formation. Tenant has all requisite power and authority under the laws of the state of its formation and its articles of organization and agreement of limited partnership or other charter documents to enter into and perform its obligations under this Lease and to consummate the transactions contemplated hereby. Tenant is duly registered or authorized, as applicable, to transact business in any jurisdiction in which the nature of the business conducted by it requires such qualification.
(b) Tenant has taken all necessary action to authorize the execution, delivery and performance of this Lease, and upon the execution and delivery of any document to be delivered by Tenant, prior to the date hereof, such document shall constitute the valid and binding obligation and agreement of Tenant, enforceable against Tenant in accordance with its terms, except as such enforceability may be limited by bankruptcy, insolvency, reorganization, moratorium or similar laws of general application affecting the rights and remedies of creditors and except to the extent that the availability of equitable relief may be subject to the discretion of the court before which any proceeding may be brought.
(c) There are no judgments presently outstanding and unsatisfied against Tenant or any of its properties, and neither Tenant nor any of its properties are involved in any material litigation at law or in equity or any proceeding before any court, or by or before any governmental or administrative agency, which litigation or proceeding could materially adversely affect Tenant, and no such material litigation or proceeding is, to the knowledge of Tenant, threatened against Tenant and no investigation looking toward such a proceeding has begun or is contemplated.
(d) To the knowledge of Tenant, neither this Lease nor any other document, certificate or statement furnished to Landlord by or on behalf of Tenant in connection with the transaction contemplated herein contains any untrue statement of a material fact or omits to state a material fact necessary in order to make the statements contained herein or therein not misleading. There is no fact or condition which materially and adversely affects the business, operations, affairs, properties or condition of Tenant which has not been set forth in this Lease or in other documents, certificates or statements furnished to Landlord in connection with the transaction contemplated hereby.
(e) All employees of Tenant or any Affiliate, if any, are solely employees of Tenant or such Affiliate and not Landlord. Neither Tenant nor any Affiliate of Tenant is Landlord’s agent for any purpose in regard to Tenant’s or any Affiliate of Tenant’s employees or otherwise. Further, Tenant expressly acknowledges and agrees that Landlord does not exercise any direction or control over the employment policies or employment decisions of Tenant or any Affiliate of Tenant.
(f) Tenant has not (i) made any contributions, payments or gifts to or for the private use of any governmental official, employee or agent where either the payment or the purpose of such contribution, payment or gift is illegal under the laws of the United States or the jurisdiction in which made, (ii) established or maintained any unrecorded fund or asset for any purpose or made any false or artificial entries on its books or (iii) made any payments to any person with the intention or understanding that any part of such payment was to be used for any purpose other than that described in the documents supporting the payment. Tenant shall not take any such actions during the Term of this Lease.
Requirements of Tenant’s Agents Each of Tenant's Agents shall guarantee to Tenant and for the benefit of Landlord that the portion of the Tenant Improvements for which it is responsible shall be free from any defects in workmanship and materials for a period of not less than one (1) year from the date of completion thereof. Each of Tenant's Agents shall be responsible for the replacement or repair, without additional charge, of all work done or furnished in accordance with its contract that shall become defective within one (1) year after the later to occur of (i) completion of the work performed by such contractor or subcontractors and (ii) the Lease Commencement Date. The correction of such work shall include, without additional charge, all additional expenses and damages incurred in connection with such removal or replacement of all or any part of the Tenant Improvements, and/or the Building and/or common areas that may be damaged or disturbed thereby. All such warranties or guarantees as to materials or workmanship of or with respect to the Tenant Improvements shall be contained in the Contract or subcontract and shall be written such that such guarantees or warranties shall inure to the benefit of both Landlord and Tenant, as their respective interests may appear, and can be directly enforced by either. Tenant covenants to give to Landlord any assignment or other assurances which may be necessary to effect such right of direct enforcement.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Construction Representatives Landlord appoints the following person(s) as Landlord's representative ("Landlord's Representative") to act for Landlord in all matters covered by this Work Letter: ------------------------ ------------------------ ------------------------ Tenant appoints the following person(s) as Tenant's representative ("Tenant Representative") to act for Tenant in all matters covered by this Work Letter. ------------------------ ------------------------ ------------------------ All communications with respect to the matters covered by this Work Letter are to be made to Landlord's Representative or Tenant's Representative, as the case may be, in writing, in compliance with the notice provisions of the Lease. Either party may change its representative under this Work Letter at any time by written notice to the other party in compliance with the notice provisions of the Lease.
Tenant Representations Each person executing this Amendment on behalf of Tenant represents and warrants to Landlord that: (a) Tenant is properly formed and validly existing under the laws of the state in which Tenant is formed and Tenant is authorized to transact business in the state in which the Building is located; (b) Tenant has full right and authority to enter into this Amendment and to perform all of Tenant’s obligations hereunder; and (c) each person (and both persons if more than one signs) signing this Amendment on behalf of Tenant is duly and validly authorized to do so.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
