Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Commencement Date The Subcontractor shall be permitted to begin the Services on ______________________, 20____ (“Commencement Date”).
Date of Lease July 8, 2002
Termination of Lease (a) Landlord and Tenant hereby agree that, effective as of the Termination Date, the Lease and the term thereof shall terminate and expire, and Tenant’s estate in and right of possession to the Premises shall terminate and be wholly extinguished, as if said Termination Date was originally set forth in the Lease as the expiration date thereunder. Effective as of the Termination Date, neither Landlord nor Tenant shall have any further rights or obligations under the Lease, except as provided in this Agreement. Effective as of the Termination Date, Landlord and Tenant for themselves and their predecessors-in-interest, successors and assigns, do hereby release and forever discharge each other, their successors and assigns, from all actions, causes of action, sums of money, covenants, agreements, promises, damages, judgments, claims and demands whatsoever in law or in equity which each against the other ever had, now has, or which they or their respective predecessors, successors or assigns hereafter may have, upon or by reason of any matter, cause or thing whatsoever from the beginning of the world through the Termination Date arising out of or in connection with the Lease or the Premises, or the Building; provided that (A) neither party shall be released from any of its obligations under this Agreement (and this Agreement shall survive the termination of the Lease), (B) neither Landlord or Tenant shall be released from any indemnification obligations that accrued under the Lease prior to the Termination Date and (C) the provisions of Section 8.13 and Section 8.21 of the Lease shall survive the termination of the Lease. Effective as of the Termination Date, Landlord shall be entitled to lease the Premises to any person or entity, or take any other action with respect thereto, free from any claim of Tenant or any person or entity claiming through Tenant.
(b) On or prior to the Termination Date, Tenant agrees to surrender unto Landlord and its successors and assigns, and Landlord agrees to accept, the Premises in its “as is” condition.
(c) In consideration of this Agreement and the termination of the Lease, Tenant agrees to permit the letter of credit in the amount of $8,698,662.00 issued by Citibank, N.A. (the “Letter of Credit”) which Letter of Credit Landlord is presently holding as security under the Lease, to be drawn down for the payment of the following sums: (i) $7,800,000.00 (the “Termination Fee”) to be drawn down and paid to Landlord in consideration of the termination of the Lease and the other transactions contemplated by this Agreement; and (ii) $898,662.00, representing the balance of the proceeds of the Letter of Credit shall be paid to Tenant. Tenant hereby authorizes Landlord to draw on the Letter of Credit and the entire proceeds of the Letter of Credit (the “Proceeds”) and Landlord agrees to deliver Tenant’s share of the Proceeds described in clause (ii) above to Tenant’s bank account within three (3) Business Days of Landlord’s receipt of the entire Proceeds in accordance with Tenant’s wire instructions attached hereto as Exhibit A. Except as otherwise set forth in this Agreement, it is agreed that in no event shall Tenant at any time be entitled to receive any other sums from Landlord in connection with the Lease, including, without limitation, all or any portion of the Work Allowance or any reimbursement of any amounts previously paid by Tenant to Landlord in connection with the construction of the Terrace Space. Contemporaneously herewith, Landlord shall deliver a sight draft to the issuer of the Letter of Credit in order to obtain payment of the Proceeds, which sight draft shall provide for the Proceeds to be paid to Landlord’s bank account, as designated by Landlord. Tenant hereby agrees to cooperate with Landlord and execute any and all documents required by the issuing bank in order to facilitate Landlord’s efforts to draw down on the Proceeds of the Letter of Credit. The effectiveness of the surrender and termination provided for in this Agreement is subject to, and conditioned upon, Landlord’s receipt of the Termination Fee in accordance with the terms hereof. If Landlord does not receive the Termination Fee in accordance with the terms hereof, then the termination of the Lease shall automatically be null and void and of no further force or effect and the Lease shall continue in full force and effect as if this Agreement had never been entered into.
(d) Tenant shall be responsible for, and shall indemnify Landlord for, any and all transfer taxes, sales taxes or other taxes or similar charges imposed by any federal, state or local governmental authority or under any Law arising from or relating to this Agreement, the Termination Fee or any of the other transactions hereunder. Tenant will execute and deliver to Landlord a New York State Form TP 584 and a New York City Form RPT.
(e) Landlord and Tenant agree that the disgorgement of any portion of the Termination Fee or the avoidance in whole or in part of this Agreement, under any applicable law, including, but not limited to, chapter 5 of title 11 of the United States Code (the "Bankruptcy Code"), shall be considered a breach of this Agreement by Tenant and shall entitle Landlord to seek the full amount of the Obligations and any other damages to which Landlord is entitled under the Lease from Tenant resulting from the breach of this Agreement.
Commencement of Leave Parental leave must commence no later than the first anniversary date of the birth or adoption of the child or of the date on which the child comes into the actual care and custody of the employee. The employee will decide when his or her parental leave is to commence.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date in the Tenant Improvement Work Readiness Condition for construction by Tenant of the Tenant Improvements (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Tenant Improvements” and “Tenant Improvement Work Readiness Condition” shall have the meanings set forth for such terms in the work letter at here to as Exhibit C (the “Work Letter”). If neither Landlord nor Tenant elects to void this Lease within 10 business days of the lapse of such 120 day period (as may be extended by Force Majeure delays), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Diego county (any such order or mandate, a “Government Mandate”), then, to the extent such Government Mandate precludes construction of the Core & Shell (as defined in the Work Letter), the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of the Core & Shell. 3115 Xxxxxxxxxx/Erasca - Page 3 The “Commencement Date” shall be date that Landlord Delivers the Premises to Tenant in Tenant Improvement Work Readiness Condition. The “Rent Commencement Date” shall be the date that is 180 days after the Commencement Date (which is anticipated to be February 1, 2022, based on the Target Commencement Date of August 1, 2021); provided, however, that the Rent Commencement Date shall be delayed 1 day for each day after the Commencement Date that a Government Mandate that restricts construction activities in San Diego county is in effect to the extent that such Government Mandate precludes such construction of the Tenant Improvements. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease. Except as set forth in the Work Letter: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. Notwithstanding the foregoing, for the period of 365 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to Building Systems (as defined in Section 13), serving the Premises unless Tenant or any Tenant Party was responsible for the cause of such repair or Tenant was responsible for the construction of such Building Systems as part of the Tenant Improvements, in which case Tenant shall pay the cost. In addition, Tenant shall be entitled to the benefit of any warranties issued to Landlord in connection with the Core & Shell for the terms of such warranties to the extent affecting the Premises. Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.
Extension of Lease Term The Original Lease Term is hereby extended for a period of eighteen (18) months continuing through and including November 30, 2022 (the “Extension Term” and the Original Lease Term as so extended by the Extension Term, the “Lease Term”).
