Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing. (b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time. (c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request. (d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation. (e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.
Quality Specifications SANMINA-SCI shall comply with the quality specifications set forth in its Quality Manual, incorporated by reference herein, a copy of which is available from SANMINA-SCI upon request.
Packing Specifications 7.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
DAF Specifications Developer shall submit initial specifications for the DAF, including System Protection Facilities, to Connecting Transmission Owner and NYISO at least one hundred eighty (180) Calendar Days prior to the Initial Synchronization Date; and final specifications for review and comment at least ninety (90) Calendar Days prior to the Initial Synchronization Date. Connecting Transmission Owner and NYISO shall review such specifications to ensure that the DAF are compatible with the technical specifications, operational control, and safety requirements of the Connecting Transmission Owner and NYISO and comment on such specifications within thirty (30) Calendar Days of Developer’s submission. All specifications provided hereunder shall be deemed to be Confidential Information.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
