Non-responsible Contractor The County may debar a Contractor if the Board of Supervisors finds, in its discretion, that the Contractor has done any of the following: (1) violated a term of a contract with the County or a nonprofit corporation created by the County, (2) committed an act or omission which negatively reflects on the Contractor’s quality, fitness or capacity to perform a contract with the County, any other public entity, or a nonprofit corporation created by the County, or engaged in a pattern or practice which negatively reflects on same, (3) committed an act or offense which indicates a lack of business integrity or business honesty, or (4) made or submitted a false claim against the County or any other public entity.
Responsible Contractor A responsible Contractor is a Contractor who has demonstrated the attribute of trustworthiness, as well as quality, fitness, capacity and experience to satisfactorily perform the contract. It is the County’s policy to conduct business only with responsible Contractors.
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;
CERTIFICATION REGARDING DEBARMENT, SUSPENSION, INELIGIBILITY AND VOLUNTARY EXCLUSION
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
BREACH DISCOVERY AND NOTIFICATION 17 1. Following the discovery of a Breach of Unsecured PHI, CONTRACTOR shall notify 18 COUNTY of such Breach, however both parties agree to a delay in the notification if so advised by a 19 law enforcement official pursuant to 45 CFR § 164.412. 20 a. A Breach shall be treated as discovered by CONTRACTOR as of the first day on which 21 such Breach is known to CONTRACTOR or, by exercising reasonable diligence, would have been 22 known to CONTRACTOR. 23 b. CONTRACTOR shall be deemed to have knowledge of a Breach, if the Breach is 24 known, or by exercising reasonable diligence would have known, to any person who is an employee, 25 officer, or other agent of CONTRACTOR, as determined by federal common law of agency. 26 2. CONTRACTOR shall provide the notification of the Breach immediately to the COUNTY 27 Privacy Officer. CONTRACTOR’s notification may be oral, but shall be followed by written 28 notification within twenty four (24) hours of the oral notification. 29 3. CONTRACTOR’s notification shall include, to the extent possible: 30 a. The identification of each Individual whose Unsecured PHI has been, or is reasonably 31 believed by CONTRACTOR to have been, accessed, acquired, used, or disclosed during the Breach; 32 b. Any other information that COUNTY is required to include in the notification to 33 Individual under 45 CFR §164.404 (c) at the time CONTRACTOR is required to notify COUNTY or 34 promptly thereafter as this information becomes available, even after the regulatory sixty (60) day 35 period set forth in 45 CFR § 164.410 (b) has elapsed, including: 36 1) A brief description of what happened, including the date of the Breach and the date 37 of the discovery of the Breach, if known; 1 2) A description of the types of Unsecured PHI that were involved in the Breach (such 2 as whether full name, social security number, date of birth, home address, account number, diagnosis, 3 disability code, or other types of information were involved); 4 3) Any steps Individuals should take to protect themselves from potential harm 5 resulting from the Breach; 6 4) A brief description of what CONTRACTOR is doing to investigate the Breach, to 7 mitigate harm to Individuals, and to protect against any future Breaches; and 8 5) Contact procedures for Individuals to ask questions or learn additional information, 9 which shall include a toll-free telephone number, an e-mail address, Web site, or postal address. 10 4. COUNTY may require CONTRACTOR to provide notice to the Individual as required in 11 45 CFR § 164.404, if it is reasonable to do so under the circumstances, at the sole discretion of the 12 COUNTY. 13 5. In the event that CONTRACTOR is responsible for a Breach of Unsecured PHI in violation 14 of the HIPAA Privacy Rule, CONTRACTOR shall have the burden of demonstrating that 15 CONTRACTOR made all notifications to COUNTY consistent with this Subparagraph F and as 16 required by the Breach notification regulations, or, in the alternative, that the acquisition, access, use, or 17 disclosure of PHI did not constitute a Breach. 18 6. CONTRACTOR shall maintain documentation of all required notifications of a Breach or 19 its risk assessment under 45 CFR § 164.402 to demonstrate that a Breach did not occur. 20 7. CONTRACTOR shall provide to COUNTY all specific and pertinent information about the 21 Breach, including the information listed in Section E.3.b.(1)-(5) above, if not yet provided, to permit 22 COUNTY to meet its notification obligations under Subpart D of 45 CFR Part 164 as soon as 23 practicable, but in no event later than fifteen (15) calendar days after CONTRACTOR’s initial report of 24 the Breach to COUNTY pursuant to Subparagraph F.2. above. 25 8. CONTRACTOR shall continue to provide all additional pertinent information about the
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Escrow Agent Not Responsible for Furnished Information The Escrow Agent will have no responsibility for seeking, obtaining, compiling, preparing or determining the accuracy of any information or document, including the representative capacity in which a party purports to act, that the Escrow Agent receives as a condition to a release from escrow or a transfer of escrow securities within escrow under this Agreement.
