Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
Third Party Products and Services Any third-party hardware, software and/or services that is delivered by ResMed for use either standalone or in conjunction with ResMed products and/or services, shall be subject to the third-party terms and conditions and/or license agreements between Customer and the third party. Such third-party hardware, software and/or services is provided by ResMed "AS IS," without any warranty of any kind. Any representations or warranties as to such hardware, software and/or services shall only be as granted by the applicable third parties, if any, that accompany such products and/or software and/or services. Any representations, warranties, or other similar obligations with respect to such third-party hardware, software and/or services flow directly from the third party to Customer and ResMed shall have no responsibility at all for any such representations, warranties, obligations or lack thereof.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
New Products You agree to comply with NASD Notice to Members 5-26 recommending best practices for reviewing new products.
Recipient Products Updated Project Schedule (if applicable) • Updated List of Match Funds (if applicable) • Updated List of Permits (if applicable) • Kick-off Meeting Agenda
Third Party Products 12.1 Third-party products provided to you by NCR Voyix for use with your subscription to the Service are subject to any terms provided by their supplier, including but not limited to those terms and conditions set forth in the exhibits attached hereto. Third-party terms and conditions are subject to change at any time by the supplier, and you agree that your use of such third-party products and services is governed by such supplier’s terms and conditions. You hereby release NCR Voyix from any and all liability associated with any damages or claims arising out of or related to third-party products. UNLESS NCR Xxxxx SPECIFICALLY AGREES OTHERWISE IN WRITING, YOU ACKNOWLEDGE AND AGREE THAT SUCH THIRD-PARTY PRODUCTS ARE PROVIDED “AS-IS” WITHOUT A WARRANTY FROM NCR Voyix. ACCORDINGLY, NCR Voyix EXPRESSLY DISCLAIMS ALL WARRANTIES OF ANY NATURE WITH RESPECT TO ANY SUCH THIRD-PARTY PRODUCTS, WHETHER ORAL OR WRITTEN, EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, AND NON-INFRINGEMENT OF ANY THIRD-PARTY RIGHTS.
12.2 Third-party products and services may be advertised or made available to you for purchase directly from their supplier by email or other electronic communications, including notifications made through the Service or the Account Portal. Any representations or warranties that may be provided in connection with any such third-party products or services are provided solely by their supplier. NCR Voyix will not be responsible for any of your dealings or interactions with any of those third-party suppliers.
Commercialization Intrexon shall have the right to develop and Commercialize the Reverted Products itself or with one or more Third Parties, and shall have the right, without obligation to Fibrocell, to take any such actions in connection with such activities as Intrexon (or its designee), at its discretion, deems appropriate.
Licensed Technology (a) LICENSOR is not aware of any interference, infringement, misappropriation, or other conflict with any intellectual property rights of third parties, and LICENSOR has never received any charge, complaint, claim, demand, or notice alleging any such interference, infringement, misappropriation, or violation (including any claim that LICENSOR must license or refrain from using any intellectual property rights of any third party). To the knowledge of LICENSOR, no third party has interfered with, infringed upon, misappropriated, or otherwise come into conflict with any of the LICENSED TECHNOLOGY.
(b) Exhibit A identifies each patent or registration which has been issued to LICENSOR with respect to any of the LICENSED TECHNOLOGY and identifies each pending patent application or application for registration which LICENSOR has made with respect to any of the LICENSED TECHNOLOGY. LICENSEE acknowledges that LICENSOR has previously made available to LICENSEE correct and complete copies of all such patents, registrations and applications (as amended to-date) in LICENSOR’s possession and has made available to LICENSEE correct and complete copies of all other written documentation in LICENSOR’s possession evidencing ownership and prosecution (if applicable) of each such item.
(c) Exhibit A identifies each item of LICENSED TECHNOLOGY that is assigned to LICENSOR or that LICENSOR uses pursuant to license, sublicense, agreement, or permission. LICENSOR has made available to LICENSEE correct and complete copies of all such licenses, sublicenses, agreements, patent prosecution files and permissions (as amended to-date) in LICENSOR’s possession. With respect to each item of LICENSED TECHNOLOGY required to be identified in Exhibit A and to the knowledge of LICENSOR: (i) the license, sublicense, agreement, or permission covering the item is legal, valid, binding, enforceable, and in full force and effect; (ii) the license, sublicense, agreement, or permission will continue to be legal, valid, binding, enforceable, and in full force and effect on identical terms following the consummation of the transactions contemplated hereby; (iii) no Party to the license, sublicense, agreement, or permission is in breach or default, and no event has occurred which with notice or lapse of time would constitute a breach or default or permit termination, modification, or acceleration thereunder; (iv) no party to the license, sublicense, agreement, or permission has repudiated any provision thereof; (v) the underlying item of LICENSED TECHNOLOGY is not subject to any outstanding lien or encumbrance, injunction, judgment, order, decree, ruling, or charge; (vi) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or is threatened which challenges the legality, validity, or enforceability of the underlying item of LICENSED TECHNOLOGY; and (vii) except as provided in Exhibit A, LICENSOR has not granted any license or similar right to the LICENSED TECHNOLOGY within the GENERAL FIELD or PARTHENOGENESIS FIELD.
