Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Grieve Where an employee feels that she has been aggrieved by a decision of the Employer related to promotion, demotion or transfer, the employee may grieve the decision at Step 3 of the grievance procedure in Article 9 of this Agreement within seven (7) days of being notified of the results.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Right to Defend Upon receipt of notice of any matter for which indemnification might be claimed by an Indemnified Party, the Indemnifying Party shall be entitled to defend, contest or otherwise protect against any such matter at its own cost and expense, and the Indemnified Party must cooperate in any such defense or other action. The Indemnified Party shall have the right, but not the obligation, to participate at its own expense in defense thereof by counsel of its own choosing, but the Indemnifying Party be entitled to control the defense unless the Indemnified Party has relieved the Indemnifying Party from liability with respect to the particular matter or the Indemnifying Party fails to assume defense of the matter. In the event the Indemnifying Party shall fail to defend, contest or otherwise protect in a timely manner against any matter, the Indemnified Party shall have the right, but not the obligation, thereafter to defend, contest or otherwise protect against the same and make any compromise or settlement thereof and recover the reasonable cost thereof from the Indemnifying Party including, without limitation, reasonable attorneys' fees, disbursements and all amounts paid as a result of such suit, action, investigation, claim or proceeding or the compromise or settlement thereof; provided, however, that the Indemnified Party must send a written notice to the Indemnifying Party of any such proposed settlement or compromise, which settlement or compromise the Indemnifying Party may reject, in its reasonable judgment, within ten (10) days of receipt of such notice. Failure to reject such notice within such ten (10) day period shall be deemed an acceptance of such settlement or compromise. The Indemnified Party shall have the right to effect a settlement or compromise over the objection of the Indemnifying Party; provided, that if (i) the Indemnifying Party is contesting such claim in good faith or (ii) the Indemnifying Party has assumed the defense from the Indemnified Party, the Indemnified Party waives any right to indemnity therefor. If the Indemnifying Party undertakes the defense of such matters, the Indemnified Party shall not, so long as the Indemnifying Party does not abandon the defense thereof, be entitled to recover from the Indemnifying Party any legal or other expenses subsequently incurred by the Indemnified Party in connection with the defense thereof other than the reasonable costs of investigation undertaken by the Indemnified Party with the prior written consent of the Indemnifying Party.
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
TEACHERS’ RIGHTS A. Pursuant to the Employer-Employee Relations Act, the Board and the Association agree that every member of the unit shall have the right freely to organize, join and support the Association and its affiliates for the purpose of engaging in collective negotiations and other concerted activities for mutual aid and protection, or to refrain from such activities. The Board and the Association undertake and agree that they shall not directly or indirectly discourage or deprive or coerce any teacher in the enjoyment of any rights conferred by the Employer-Employee Relations Act, or other laws of New Jersey or the constitutions of New Jersey or the United States.
B. Nothing contained herein shall be construed to deny or restrict to any teacher such rights as he/she may have under New Jersey School Laws or other applicable laws and regulations. The rights granted to teachers hereunder shall be deemed to be in addition to those provided elsewhere.
C. No teacher shall be disciplined, reprimanded or reduced in rank or compensation without just cause. Any such action asserted by the Board, or any agent or representative thereof, shall be subject to the grievance procedure herein set forth. For purposes of this provision, discharge, removal, or non-renewal shall not be considered as discipline, reprimand or reduction in rank or compensation.
D. Whenever any teacher is required to appear before any Administrator or Supervisor, the Superintendent, Board or any committee thereof for a meeting or conference, the purpose of which adversely concerns the continuance of that teacher in his/her office, position, or employment or adversely concerns salary or any increments pertaining thereto, he/she shall be given prior written notice of the reason for such meeting or conference and shall be entitled to have a representative of the Association present to advise and represent him/her during such meeting or conference, provided that no unreasonable delay shall be incurred in the scheduling of such meeting due to a lack of representation.
E. The Board shall provide a job description of co- curricular jobs for which compensation is provided. This description shall be prepared by the Board of Education in consultation with the Association.
Right to Assign Each Lender may sell, transfer, negotiate or assign (a “Sale”) all or a portion of its rights and obligations hereunder (including all or a portion of its Commitments and its rights and obligations with respect to Loans and Letters of Credit) to (i) any existing Lender (other than a Non-Funding Lender or Impacted Lender), (ii) any Affiliate or Approved Fund of any existing Lender (other than a Non-Funding Lender or Impacted Lender) or (iii) any other Person (other than the Borrower and its Subsidiaries, a natural Person or, so long as no Event of Default is then continuing, a Disqualified Institution) with the prior written consent (which consent shall not be unreasonably withheld or delayed, except in connection with a proposed assignment to any Disqualified Institution) of the Administrative Agent, and, as long as no Event of Default is continuing, the prior written consent of the Borrower, and, in the case of any Sale of a Revolving Loan, Letter of Credit or Revolving Loan Commitment, the Revolver Agent and each L/C Issuer that is a Lender (which such consent of L/C Issuer and the Borrower shall be deemed to have been given unless an objection is delivered to the Administrative Agent within ten (10) Business Days after notice of a proposed Sale is delivered to the Borrower) (each of the Persons described in clauses (i), (ii) and (iii) being called herein an “Eligible Assignee”); provided, however, that (w) such Sales do not have to be ratable between the Revolving Loan and the Term Loan but must be ratable among the obligations owing to and owed by such Lender with respect to the Revolving Loans or the Term Loan, (x) for each Loan, the aggregate outstanding principal amount (determined as of the effective date of the applicable Assignment) of the Loans, Commitments and Letter of Credit Obligations subject to any such Sale shall be in a minimum amount of $1,000,000, unless such Sale is made to an existing Lender or an Affiliate or Approved Fund of any existing Lender, is of the assignor’s (together with its Affiliates and Approved Funds) entire interest in such facility or is made with the prior written consent of the Borrower (to the extent Borrower’s consent is otherwise required) and the Administrative Agent and, in the case of any Sale of a Revolving Loan, Letter of Credit or Revolving Loan Commitment, the Revolver Agent, (y) interest accrued, prior to and through the date of any such Sale may not be assigned, and (z) such Sales by Lenders who are Non-Funding Lenders due to clause (a) of the definition of Non-Funding Lender shall be subject to the Administrative Agent’s prior written consent in all instances, unless in connection with such sale, such Non-Funding Lender cures, or causes the cure of, its Non-Funding Lender status as contemplated in subsection 1.11(e)(v). The Administrative Agent’s refusal to accept a Sale to a Credit Party, a holder of other Indebtedness of a Credit Party or an Affiliate of such a holder, or to a Person that would be a Non-Funding or Impacted Lender, or the imposition of conditions or limitations (including limitations on voting) upon Sales to such Persons, shall not be deemed to be unreasonable. In no event shall any Lender Sell any Loan or Commitment to Borrower or any Subsidiary thereof and any such purported Sale shall be null and void.
Licensee’s Right to Terminate Licensee may, at its option, without prejudice to any other remedies it may have, terminate this agreement by giving written notice of such termination to Licensor as follows: (a) immediately, in the event that Licensor abandons the Licensed Marks or otherwise ceases to support the Licensed Marks in Licensor's business; or (b) immediately in the event of the occurrence of a Bankruptcy with respect to Licensor; or (c) immediately in the event of an occurrence of termination pursuant to Section 13.2(d).
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
