Project Approvals The Borrower will promptly obtain all Project approvals not heretofore obtained by the Borrower (including those listed and described on Exhibit “N” hereto and any other Project Approvals which may hereafter become required, necessary or desirable) and will furnish the Lender with evidence that the Borrower has obtained such Project Approvals promptly upon its request. The Borrower will give all such notices to, and take all such other actions with respect to, such Governmental Authority as may be required under applicable Requirements to construct the Improvements and to use, occupy and operate the Project following the completion of the construction of the Improvements. The Borrower will also promptly obtain all utility installations and connections required for the operation and servicing of the Project for its intended purposes, and will furnish the Lender with evidence thereof. The Borrower will duly perform and comply with all of the terms and conditions of all Project Approvals obtained at any time, including all Project Approvals listed and described on Exhibit “Q” hereto.
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.
Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.
Project Agreements Provided that where the company commences work on a project where a site agreement exists to which the company is contractually obligated or where a site agreement exists between the union and the client or their agent that provides for higher rates of pay and conditions, the conditions contained in any such site agreement will take precedence over this Agreement for the duration of the project.
Design Development Documents See Section 2, Part 1, Article 2.1.5.
Project Agreement 1.1 If applicable, the Department will recommend approval of the project by the Federal Highway Administration.
1.2 The Sponsor agrees to comply with Title VI of the Civil Rights Act of 1964, 78 Stat. § 252, 42 U.S.C. § 2000d et seq., and all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, Part 21 - “Nondiscrimination in federally assisted programs of the Department of Transportation - effectuation of Title VI of the Civil Rights Act 1964".
1.3 The DEPARTMENT and SPONSOR mutually recognize that each party is a governmental entity subject to the provisions of the Governmental Tort Claims Act (51 O.S. § 151 et seq.). The DEPARTMENT and SPONSOR hereby mutually agree that each is and may be held severally liable for any and all claims, demands, and suits in law or equity, of any nature whatsoever, paying for damages or otherwise, arising from any negligent act or omission of any of their respective employees, agents or contractors which may occur during the prosecution or performance of this Agreement to the extent provided in the Governmental Tort Claims Act. Each party agrees to severally bear all costs of investigation and defense of claims arising under the Governmental Tort Claims Act and any judgments which may be rendered in such cause to the limits provided by law. Nothing in this section shall be interpreted or construed to waive any legal defense which may be available to a party or any exemption, limitation or exception which may be provided by the Governmental Tort Claims Act.
1.4 The Sponsor understands that should it fail to fulfill its responsibilities under this Agreement, such a failure will disqualify the Sponsor from future Federal-aid funding participation on any proposed project. Federal-aid funds are to be withheld until such a time as an engineering staff, satisfactory to the Department has been properly established and functioning, the deficiencies in regulations have been corrected or the improvements to be constructed under this Agreement are brought to a satisfactory condition of maintenance.
Development Plans Shipper has provided Gatherer with a report attached hereto as Exhibit D (the “Current Development Plan”) describing in detail, as of January 1, 2017, the planned development, drilling, and production activities to take place with respect to Dedicated Production for the applicable Development Period. The information contained in the TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Current Development Plan is broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by the Current Development Plan, on a Quarter-by-Quarter basis, and with respect to the remaining Years covered by the Current Development Plan, on a Year-by-Year basis. The Current Development Plan attached hereto has been approved by the Parties.
(a) From time to time during each Year of the Term, the Parties shall meet to discuss the planned development, drilling, and production activities that Shipper expects to take place with respect to Dedicated Production for the then-applicable Development Period. Shipper and Gatherer shall each make their respective representatives available to participate in such meetings and discussions. No later than August 1 of each such Year, Shipper shall provide (or cause to be provided) to Gatherer a proposed update of the then-currently agreed Development Plan, prepared on the same basis as the Current Development Plan and describing in detail the planned development, drilling, and production activities to take place with respect to Dedicated Production for the then-applicable Development Period (any such update, an “Updated Development Plan” and, together with the Current Development Plan, each, a “Development Plan”). Notwithstanding anything herein to the contrary, in no event shall Gatherer be required to agree to any Updated Development Plan and corresponding updated Gathering System Plan that contains a Committed Build-Out that (i) has a corresponding Target Completion Date that occurs after the end of the Initial Term, and (ii) Gatherer, in its sole discretion, does not wish to approve.
(b) Each proposed Development Plan shall include information as to the following, in each case, broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by such Development Plan, on a Quarter-by-Quarter basis, and, with respect to the remaining Years covered by such Development Plan, on a Year-by-Year basis:
(i) all Xxxxx that, as of the date such Development Plan was delivered, are currently in existence and (A) the production therefrom is being delivered into the Gathering System, or (B) are awaiting connection to the Gathering System;
(ii) the Xxxxx that are expected to be drilled during the time period covered by such Development Plan (each such Well reflected in such Development Plan, a “Planned Well”), and the estimated timing of the drilling of such Planned Xxxxx;
(iii) forward-looking production estimates for the applicable time period covered by such Development Plan for all Shipper Gas (A) that Shipper reasonably and in good faith believes will become owned or Controlled by Shipper during the time period covered by such Development Plan, and/or (B) that will be produced from (I) in the aggregate, all Xxxxx then-existing and (II) in the aggregate, any Planned Xxxxx included in such Development Plan (such collective estimates described in subsections (A) and (B), both with respect to a particular Quarter and an entire Year, the “Dedicated Production Estimates”); TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
(iv) forward-looking estimates for the applicable time period covered by such Development Plan of the aggregate volumes of those Shipper Injected Liquids that Shipper intends to Tender to the Injection Points hereunder to receive the System Services (such estimates, both with respect to a particular Quarter and an entire Year, the “System Liquids Estimates” and, together with the Dedicated Production Estimates, the “System Production Estimates”);
(v) (A) each new receipt point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such receipt point, including those located at the site of a Planned Well, a “Planned Receipt Point”), (B) each Receipt Point at which Shipper expects to Tender Shipper Gas and/or Shipper Injected Liquids reflected in such Development Plan into the Gathering System, and (C) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to Tender at each such Receipt Point and Planned Receipt Point;
(vi) the earliest date on which each Planned Well included in the Development Plan is estimated to be completed and producing, which date shall not be earlier than three Months after the January 1st that is immediately subsequent to the date that the Development Plan that initially reflected such Planned Well was delivered to Gatherer hereunder;
(vii) the anticipated characteristics of the production from the Xxxxx and Planned Xxxxx reflected in such Development Plan (including liquids content and gas and liquids composition) and the projected production volumes and production pressures applicable thereto; provided that Shipper may utilize the existing and historical production information from similarly situated Xxxxx;
(viii) (A) each new delivery point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such delivery point, a “Planned Delivery Point”), (B) each Delivery Point at which Shipper expects Shipper Gas produced from the Xxxxx and Planned Xxxxx reflected in such Development Plan to be redelivered to Shipper, (C) each Delivery Point at which Shipper expects any Drip Liquids allocated to Shipper in accordance with this Agreement and/or Shipper Injected Liquids to be redelivered to Shipper, and (D) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to be redelivered to Shipper at each such Delivery Point and Planned Delivery Point;
(ix) any (A) proposed revision to the then-existing Dedicated Area and/or any then-existing Dedicated Contract and/or (B) any new contract that Shipper proposes to be a Dedicated Contract; and
(x) other information reasonably requested by Gatherer that is relevant to the design, construction, and operation of the Gathering System, including (A) any Subsystem Extension proposed by Shipper, (B) the relevant Receipt Point, Planned Receipt Point, Delivery Point and Planned Delivery Point facilities applicable to such TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Development Plan, and (C) any treating, processing, or liquids handling facilities proposed by Shipper that may be required for any Shipper Gas and/or Shipper Injected Liquids to meet applicable Downstream Facility specifications at the Delivery Points.
Project Plans The Contractor: must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and for the purposes of subparagraph (i), must: prepare Project Plans based, where applicable, on the draft Project Plans lodged by the Contractor in its tender for the Contractor's Activities, and otherwise in accordance with the requirements of the Contract and submit them to the Contract Administrator so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event no later than the number of days specified in the Contract Particulars after the Award Date for each Project Plan; not commence any of the Contractor's Activities to which any Project Plan applies, unless the Contract Administrator has had the number of days specified in the Contract Particulars for each Project Plan to review the Project Plan and has not rejected the Project Plan; if any Project Plan is rejected, submit an amended Project Plan to the Contract Administrator; in any event, finalise each Project Plan so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event in accordance with the requirements of the Contract to the satisfaction of the Contract Administrator; after each Project Plan has been finalised: regularly review, update and amend each Project Plan in accordance with the process set out in each Project Plan (and otherwise at least on each anniversary of the Award Date); update or amend a Project Plan on request of the Contract Administrator; and continue to correct any defects in or omissions from a Project Plan (whether identified by the Contract Administrator or the Contractor), and submit an updated or amended Project Plan to the Contract Administrator, after which: the Contractor must continue to comply with the requirements of the then current Project Plan until the process in subparagraph (ii) has been completed in respect of the updated or amended Project Plan; and subsubparagraphs B - E will apply (to the extent applicable); and document and maintain detailed records of all: reviews, updates, amendments and submissions of each Project Plan; audits or other monitoring of each Project Plan; and training and awareness programs and communications provided to Contractor and subcontractor personnel in respect of each Project Plan (including each updated or amended Project Plan). The Contractor will not be relieved from compliance with any of its obligations under the Contract or otherwise at law or in equity as a result of: the implementation of, and compliance with, the requirements of any Project Plan; any direction by the Contract Administrator concerning a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; any audit or other monitoring by the Contract Administrator or anyone else acting on behalf of the Commonwealth of the Contractor's compliance with a Project Plan; or any failure by the Contract Administrator, or anyone else acting on behalf of the Commonwealth, to detect any defect in or omission from a Project Plan including where any such failure arises from any negligence on the part of the Contract Administrator or other person.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
