Project Changes 1.8.1. All changes shall be administered per the UGC.
1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders.
1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal.
1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form.
1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date".
1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order.
1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order.
1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.
Development Plans Shipper has provided Gatherer with a report attached hereto as Exhibit D (the “Current Development Plan”) describing in detail, as of January 1, 2017, the planned development, drilling, and production activities to take place with respect to Dedicated Production for the applicable Development Period. The information contained in the TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Current Development Plan is broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by the Current Development Plan, on a Quarter-by-Quarter basis, and with respect to the remaining Years covered by the Current Development Plan, on a Year-by-Year basis. The Current Development Plan attached hereto has been approved by the Parties.
(a) From time to time during each Year of the Term, the Parties shall meet to discuss the planned development, drilling, and production activities that Shipper expects to take place with respect to Dedicated Production for the then-applicable Development Period. Shipper and Gatherer shall each make their respective representatives available to participate in such meetings and discussions. No later than August 1 of each such Year, Shipper shall provide (or cause to be provided) to Gatherer a proposed update of the then-currently agreed Development Plan, prepared on the same basis as the Current Development Plan and describing in detail the planned development, drilling, and production activities to take place with respect to Dedicated Production for the then-applicable Development Period (any such update, an “Updated Development Plan” and, together with the Current Development Plan, each, a “Development Plan”). Notwithstanding anything herein to the contrary, in no event shall Gatherer be required to agree to any Updated Development Plan and corresponding updated Gathering System Plan that contains a Committed Build-Out that (i) has a corresponding Target Completion Date that occurs after the end of the Initial Term, and (ii) Gatherer, in its sole discretion, does not wish to approve.
(b) Each proposed Development Plan shall include information as to the following, in each case, broken out on a Subsystem-by-Subsystem basis and, with respect to the first three Years covered by such Development Plan, on a Quarter-by-Quarter basis, and, with respect to the remaining Years covered by such Development Plan, on a Year-by-Year basis:
(i) all Xxxxx that, as of the date such Development Plan was delivered, are currently in existence and (A) the production therefrom is being delivered into the Gathering System, or (B) are awaiting connection to the Gathering System;
(ii) the Xxxxx that are expected to be drilled during the time period covered by such Development Plan (each such Well reflected in such Development Plan, a “Planned Well”), and the estimated timing of the drilling of such Planned Xxxxx;
(iii) forward-looking production estimates for the applicable time period covered by such Development Plan for all Shipper Gas (A) that Shipper reasonably and in good faith believes will become owned or Controlled by Shipper during the time period covered by such Development Plan, and/or (B) that will be produced from (I) in the aggregate, all Xxxxx then-existing and (II) in the aggregate, any Planned Xxxxx included in such Development Plan (such collective estimates described in subsections (A) and (B), both with respect to a particular Quarter and an entire Year, the “Dedicated Production Estimates”); TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**).
(iv) forward-looking estimates for the applicable time period covered by such Development Plan of the aggregate volumes of those Shipper Injected Liquids that Shipper intends to Tender to the Injection Points hereunder to receive the System Services (such estimates, both with respect to a particular Quarter and an entire Year, the “System Liquids Estimates” and, together with the Dedicated Production Estimates, the “System Production Estimates”);
(v) (A) each new receipt point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such receipt point, including those located at the site of a Planned Well, a “Planned Receipt Point”), (B) each Receipt Point at which Shipper expects to Tender Shipper Gas and/or Shipper Injected Liquids reflected in such Development Plan into the Gathering System, and (C) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to Tender at each such Receipt Point and Planned Receipt Point;
(vi) the earliest date on which each Planned Well included in the Development Plan is estimated to be completed and producing, which date shall not be earlier than three Months after the January 1st that is immediately subsequent to the date that the Development Plan that initially reflected such Planned Well was delivered to Gatherer hereunder;
(vii) the anticipated characteristics of the production from the Xxxxx and Planned Xxxxx reflected in such Development Plan (including liquids content and gas and liquids composition) and the projected production volumes and production pressures applicable thereto; provided that Shipper may utilize the existing and historical production information from similarly situated Xxxxx;
(viii) (A) each new delivery point (including the location thereof) proposed by Shipper with respect to the System Production Estimate reflected in such Development Plan (each such delivery point, a “Planned Delivery Point”), (B) each Delivery Point at which Shipper expects Shipper Gas produced from the Xxxxx and Planned Xxxxx reflected in such Development Plan to be redelivered to Shipper, (C) each Delivery Point at which Shipper expects any Drip Liquids allocated to Shipper in accordance with this Agreement and/or Shipper Injected Liquids to be redelivered to Shipper, and (D) the estimated portion of the System Production Estimate contained in such Development Plan that Shipper expects to be redelivered to Shipper at each such Delivery Point and Planned Delivery Point;
(ix) any (A) proposed revision to the then-existing Dedicated Area and/or any then-existing Dedicated Contract and/or (B) any new contract that Shipper proposes to be a Dedicated Contract; and
(x) other information reasonably requested by Gatherer that is relevant to the design, construction, and operation of the Gathering System, including (A) any Subsystem Extension proposed by Shipper, (B) the relevant Receipt Point, Planned Receipt Point, Delivery Point and Planned Delivery Point facilities applicable to such TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH TWO ASTERISKS (**). Development Plan, and (C) any treating, processing, or liquids handling facilities proposed by Shipper that may be required for any Shipper Gas and/or Shipper Injected Liquids to meet applicable Downstream Facility specifications at the Delivery Points.
Development Phase contractual phase initiated with the approval of ANP for the Development Plan and which is extended during the Production Phase while investments in xxxxx, equipment, and facilities for the Production of Oil and Gas according to the Best Practices of the Oil Industry are required.
Project Implementation The Borrower shall:
Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.
Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Concession Area, including its abandonment.
Development Activities The Development activities referred to in item “b” of paragraph 3.1 include: studies and projects of implementation of the Production facilities; drilling and completion of the Producing and injection xxxxx; and installation of equipment and vessels for extraction, collection, Treatment, storage, and transfer of Oil and Gas. The installation referred to in item “c” includes, but is not limited to, offshore platforms, pipelines, Oil and Gas Treatment plants, equipment and facilities for measurement of the inspected Production, wellhead equipment, production pipes, flow lines, tanks, and other facilities exclusively intended for extraction, as well as oil and gas pipelines for Production Outflow and their respective compressor and pumping stations.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
