ADDITIONAL SPECIAL CONTRACT CONDITIONS A. Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Initial Forecasts/Trunking Requirements Because Verizon’s trunking requirements will, at least during an initial period, be dependent on the Customer segments and service segments within Customer segments to whom CSTC decides to market its services, Verizon will be largely dependent on CSTC to provide accurate trunk forecasts for both inbound (from Verizon) and outbound (to Verizon) traffic. Verizon will, as an initial matter, provide the same number of trunks to terminate Reciprocal Compensation Traffic to CSTC as CSTC provides to terminate Reciprocal Compensation Traffic to Verizon. At Verizon’s discretion, when CSTC expressly identifies particular situations that are expected to produce traffic that is substantially skewed in either the inbound or outbound direction, Verizon will provide the number of trunks CSTC suggests; provided, however, that in all cases Verizon’s provision of the forecasted number of trunks to CSTC is conditioned on the following: that such forecast is based on reasonable engineering criteria, there are no capacity constraints, and CSTC’s previous forecasts have proven to be reliable and accurate.
C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Trunk Forecasting Requirements 14.2.1 Initial trunk forecast requirements. At least ninety (90) days before initiating interconnection in a LATA, Alltel shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.
PAYMENT TERMS/PRE-PAYMENT/QUANTITY DISOUNTS If discounts for accelerated payment, pre-payment, progress payment, or quantity discounts are offered, they must be clearly indicated in the Contractor’s submission prior to contract award. The applicability or acceptance of these terms is at the discretion of the Customer.
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.