Disbursement of Per Pupil Funding Sample Clauses

Disbursement of Per Pupil Funding. Commencing on July 1 of each fiscal year of the Contract term, PPF as described in Section 7.1.A shall be disbursed to the School in monthly installments, subject, however, to annual appropriation and the District’s receipt of funding. July through November funding shall be based on the School’s enrollment projections submitted in accordance with Section 7.4. Funding for December and subsequent months of each fiscal year shall be adjusted in accordance with Section 7.2.B. Funds shall be disbursed within five (5) days of being received by the District.
Sample 1
AutoNDA by SimpleDocs

Related to Disbursement of Per Pupil Funding

  • Per-pupil Funding The School's non-facility general fund per-pupil funding shall be as defined in Sec. 302D-28, HRS. The Commission shall distribute the School's per-pupil allocation each fiscal year pursuant to Sec. 302D-28(f), HRS, and shall provide the School with the calculations used to determine the per-pupil amount each year. All funds distributed to the School from the Commission shall be used solely for the School's educational purposes as appropriated by the Legislature, and the School shall have discretion to determine how such funding shall be allocated at the school level to serve those purposes subject to applicable laws and this Contract.

  • DEFENSE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES 252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)

  • FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE I (JUL 1985) 52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996) - ALTERNATE II (JUL 1985) 52.246-03 INSPECTION OF SUPPLIES -- COST-REIMBURSEMENT (MAY 2001) 52.246-04 INSPECTION OF SERVICES -- FIXED-PRICE (AUG 1996) 52.246-05 INSPECTION OF SERVICES -- COST-REIMBURSEMENT (APR 1984) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) 52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) - ALTERNATE I (APR 1984) 52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984) 52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

  • Printing of Collective Agreement The Hospital and Union agree that the cost of printing the collective agreements will be shared equally between the parties. The Union will be responsible for having the collective agreements printed in booklet format within sixty (60) days of its signing by both parties.

  • Reimbursement of General Partner (a) Except as provided in this Section 6.5 and elsewhere in this Agreement (including the provisions of Articles 5 and 6 regarding distributions, payments, and allocations to which it may be entitled), the General Partner shall not be compensated for its services as general partner of the Partnership. (b) The General Partner shall be reimbursed on a monthly basis, or such other basis as the General Partner may determine in its sole and absolute discretion, for all Administrative Expenses incurred by the General Partner.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • PROJECT FUNDING 8.1 The Project Funding for completion of this PFA is as follows:[X]

  • Reimbursement of VAT Where under this contract one party is to reimburse or indemnify the other in respect of any payment made or cost incurred by the other, the first party shall also reimburse any VAT paid by the other which forms part of its payment made or cost incurred to the extent such VAT is not available for credit for the other party (or for any person with whom the indemnified party is treated as a member of a group for VAT purposes) under sections 25 and 26 of the Value Added Tax Xxx 0000.

  • Project Administration Designation Pursuant to Paragraph (B) of Rule 164-1-21 of the Administrative Code, the Recipient shall designate its Chief Executive Officer, Chief Fiscal Officer and Project Manager in Appendix B of this Agreement. Changes in these designations must be made in writing.

  • Contents of Personnel File A. Adverse statements prepared by the County shall not be included in an employee's official personnel file unless a copy is provided to the employee. B. An employee shall have the right to inspect and review the contents of his or her official personnel file at reasonable intervals. C. In addition, an employee shall have the right to inspect and review the contents of his or her official personnel file in any case where the employee has a grievance related to performance; to a performance evaluation; or is contesting his or her suspension or discharge from County service. D. Letters of reference and reports concerning criminal investigations concerning the employee shall be excluded from the provisions of B. and C., above. E. An employee shall have the right to respond in writing or personal interview to any information contained in his or her official personnel file, such reply to become a permanent part of such employee's official personnel file. F. Any contents of an employee's official personnel file may be destroyed pursuant to an agreement between the Chief of Employee Relations and the employee concerned or by an order of an arbitrator, court or impartial hearing officer unless the particular item is otherwise required by law to be kept.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!