Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
Disputes – Contract A. The parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Project Manager and the County‘s Project Manager, such matter shall be brought to the attention of the County Deputy Purchasing Agent by way of the following process:
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
Disputes and Remedies 6 7.01 Agreement of the Parties 6 7.02 Operational Remedies 6 7.03 Equitable Remedies 7 7.04 Continuing Duty to Perform 7 Article VIII. Damages 7 8.01 Availability and Assessment 7 8.02 Specific Items of Liability 7
Disputes Concerning Work or Cost Any dispute concerning the work hereunder or additional costs, or any non-procurement issues shall be settled in accordance with 43 Texas Administrative Code §9.2.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.
Agreement to Arbitrate Disputes Either you or we may elect, without the other’s consent, to require that any dispute between us concerning your membership, your deposit accounts (“Accounts”) and the services related to your membership and Accounts, including but not limited to all disputes that you may raise against us, must be resolved by binding arbitration, except for those disputes specifically excluded below.
Complaints and Disputes 28.1. If the Client wishes to report a complaint, he must send an email to the Company with the completed “Complaints Form” found on the Website. The Company will try to resolve it without undue delay and according to the Company’s Complaints Procedure for Clients.
Disputes and Arbitration 22. Any dispute concerning a question of fact arising under this contract shall be disposed of by good faith negotiation between duly authorized representatives of the County, the Office of the State Auditor, and the Firm. Such a resolution shall be reduced to writing and a copy thereof mailed or furnished to the Firm and shall be final and conclusive. If a resolution cannot be reached, the Firm shall mail or furnish to the Board of Supervisors of the County and the Office of the State Auditor a written request for review. The Firm shall be afforded an opportunity to be heard and to offer evidence in support of his/her/its position on the issue in dispute and under review. The review will be handled under a three (3) person panel for arbitration composed of the Deputy State Auditor, the Director of Technical Assistance and the Director of the Financial and Compliance Audit Division. The decision of the Arbitration Panel of the Office of the State Auditor on the review shall be final and conclusive unless determined by a court of competent jurisdiction in Xxxxx County, State of Mississippi, to have been fraudulent, capricious, or so grossly erroneous as necessarily to imply bad faith, or not be supported by substantial evidence. Pending final decision of a dispute hereunder, the Firm shall proceed diligently with the performance of the duties and obligations of the contract.
