Distribution Upgrades The Connecting Transmission Owner shall design, procure, construct, install, and own the Distribution Upgrades described in Attachment 6 of this Agreement. If the Connecting Transmission Owner and the Interconnection Customer agree, the Interconnection Customer may construct Distribution Upgrades. The actual cost of the Distribution Upgrades, including overheads, shall be directly assigned to the Interconnection Customer. The Interconnection Customer shall be responsible for its share of all reasonable expenses, including overheads, associated with owning, operating, maintaining, repairing, and replacing the Distribution Upgrades, as set forth in Attachment 6 to this Agreement.
Network Upgrades and Distribution Upgrades The Participating TO shall design, procure, construct, install, and own the Network Upgrades and Distribution Upgrades described in Appendix A. The Interconnection Customer shall be responsible for all costs related to Distribution Upgrades. Unless the Participating TO elects to fund the capital for the Distribution Upgrades and Network Upgrades, they shall be solely funded by the Interconnection Customer.
Interim payment At the end of each of the periods indicated in Annex I the Contractor shall submit to the Agency a formal request for payment accompanied by those of the following documents which are provided for in the Special Conditions: ➢ an interim technical report in accordance with the instructions laid down in Xxxxx X; ➢ the relevant invoices indicating the reference number of the Contract and of the order or specific contract to which they refer;
Excess Payments If Tenant shall assign this Lease or sublet any part of the Premises for consideration in excess of the pro-rata portion of Rent applicable to the space subject to the assignment or sublet, then Tenant shall pay to Landlord as Additional Rent 50% of any such excess immediately upon receipt.
Developer Payments Not Taxable The Developer and Connecting Transmission Owner intend that all payments or property transfers made by Developer to Connecting Transmission Owner for the installation of the Connecting Transmission Owner’s Attachment Facilities and the System Upgrade Facilities and the System Deliverability Upgrades shall be non-taxable, either as contributions to capital, or as an advance, in accordance with the Internal Revenue Code and any applicable state income tax laws and shall not be taxable as contributions in aid of construction or otherwise under the Internal Revenue Code and any applicable state income tax laws.
Contract Distribution The Employer will provide all current and new employees with a link to the new Agreement. Each department or unit will maintain a paper copy of the contract accessible to all employees.
When Must Distributions from a Traditional IRA Begin You must begin receiving the assets in your account no later than April 1 following the calendar year in which you reach RMD age.
Distribution Protocol (1) At a time wholly within the discretion of Class Counsel, but on notice to the Settling Defendants, Class Counsel will bring motions seeking orders from the Courts approving the Distribution Protocol. The motions can be brought before the Effective Date, but the orders approving the Distribution Protocol shall be conditional on the Effective Date occurring.
Interim payments Interim payments are intended to reimburse the beneficiary for expenditure on the basis of a detailed statement of the costs incurred, once the action has reached a certain level of completion. It may clear all or part of any pre-financing. By the appropriate deadline indicated in Article I.5, the beneficiary shall submit a request for interim payment accompanied by the following documents: - an interim report on implementation of the action; - an interim financial statement of the eligible costs actually incurred, following the structure of the estimated budget; - where required by the provisions of Article I.4 on interim payment, a certificate on the action's financial statements and underlying accounts, produced by an approved auditor or, in case of public bodies, by a competent and independent public officer. The certificate shall certify, in accordance with a methodology approved by the Commission, that the costs declared by the beneficiary in the financial statements on which the request of payment is based are real, accurately recorded and eligible and that all receipts have been declared, in accordance with the agreement. The documents accompanying the request for payment shall be drawn up in accordance with the relevant provisions in Article I.5 and the annexes. The beneficiary shall certify that the information provided in his request for payment is full, reliable and true. He shall also certify that the costs incurred can be considered eligible in accordance with the agreement, that all receipts have been declared, and that his request for payment is substantiated by adequate supporting documents that can be checked. On receipt of these documents, the Commission shall have the period specified in Article I.4 in order to: - approve the interim report on implementation of the action; - ask the beneficiary for supporting documents or any additional information it deems necessary to allow the approval of the report; - reject the report and ask for the submission of a new report. Failing a written reply from the Commission within the time limit for scrutiny indicated above, the report shall be deemed to have been approved. Approval of the report accompanying the request for payment shall not imply recognition of the regularity or of the authenticity, completeness and correctness of the declarations and information it contains. Requests for additional information or a new report shall be notified to the beneficiary in writing. If additional information or a new report is requested, the time limit for scrutiny shall be extended by the time it takes to obtain this information. The beneficiary shall be informed of that request and the extension of the delay for scrutiny by means of a formal document. The beneficiary shall have the period laid down in Article I.4 to submit the information or new documents requested. Extension of the delay for approval of the report may delay the payment by the equivalent time. Where a report is rejected and a new report requested, the approval procedure described in this article shall apply. In the event of renewed rejection, the Commission reserves the right to terminate the agreement by invoking Article II.11.2 (b).
PROGRESS PAYMENT 5.4.1 After receipt by the Contract Administrator of a Proper Invoice submitted by the Contractor in accordance with 5.3 – PROPER INVOICES:
