District The public agency or the school district for which the Work is performed. The governing board of the District or its designees will act for the District in all matters pertaining to the Contract. The District may, at any time: 1.1.23.1 Direct Developer to communicate with or provide notice to the Construction Manager or the Architect on matters for which the Contract Documents indicate Developer will communicate with or provide notice to the District; and/or 1.1.23.2 Direct the Construction Manager or the Architect to communicate with or direct Developer on matters for which the Contract Documents indicate the District will communicate with or direct Developer.
District Contribution Effective January 1, 2019:
DISTRICT RIGHTS 4.1 It is understood and agreed that the District retains all of its powers and authority to direct, manage and control to the full extent of the law. Included in, but not limited to, those duties and powers are the exclusive right to: determine its organization; direct the work of its employees; determine the times and hours of operation; determine the kinds and levels of service to be provided, and the methods and means of providing them; establish its educational policies, goals and objectives; insure the rights and educational opportunities of students; determine staffing patterns; determine the number and kinds of personnel required; maintain the efficiency of District operation; determine the curriculum; build, move or modify facilities; establish budget procedures and determine budgetary allocation; determine the methods of raising revenue; contract out work as legally allowed under the Education and Government Codes; and take action on any matter in the event of an emergency. In addition, the District retains the right to hire, assign, evaluate, promote, layoff, terminate and discipline employees. 4.2 The exercise of the foregoing powers, rights, authority, duties and responsibilities by the District, the adoption of policies, rules, regulations and practices in furtherance thereof, and the use of judgment and discretion in connection therewith, shall be limited only by the specific and express terms of this Agreement, and then only to the extent such specific and express terms are in conformance with law. 4.3 The District retains its right to amend, modify or suspend policies and practices covered in this Agreement in emergency circumstances. Examples of emergency circumstances are physical catastrophe and acts of nature. Such changes, if any, will remain in effect only for the duration of the emergency. All grievance time lines expressly set forth in the Agreement will be held in abeyance while the contract is suspended. 4.4 The exercise of any right reserved to the District herein in a particular manner or the non- exercise of any such right shall not be deemed a waiver of the District's right or preclude the District from exercising their rights. 4.5 Any dispute arising out of or in any way connected with either the existence of or the exercise of any of the above described rights of the District is not subject to the grievance provisions set forth in this Agreement unless such dispute is otherwise grievable under another Article of the Agreement.
District Responsibilities With respect to all sums deducted by the District pursuant to authorization of the employee, whether for membership dues or equivalent fees, the District agrees promptly to remit such monies to the Association together with an alphabetical list of unit members for who such deductions have been made, categorizing them as to membership or non-membership in the Association, and indicating any changes in personnel from the list previously furnished.
District Approval The work completed herein must meet the approval of the District and shall be subject to the District’s general right of inspection and supervision to secure the satisfactory completion thereof.
Regulation of School District Expenses The Board regulates the reimbursement of all travel, meal, and lodging expenses in the District by resolution. No later than approval of the annual budget and when necessary, the Superintendent will recommend a maximum allowable reimbursement amount for expenses to be included in the resolution. The recommended amount should be based upon the District's budget and other financial considerations.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
SCHOOL DISTRICT RIGHTS Section 1. Inherent Managerial Rights 2 Section 2. Management Responsibilities 2 Section 3. Effect of Laws, Rules and Regulations 2 Section 4. Reservation of Managerial Rights 2
United States If you acquired the software in the United States, Washington state law governs the interpretation of this agreement and applies to claims for breach of it, regardless of conflict of laws principles. The laws of the state where you live govern all other claims, including claims under state consumer protection laws, unfair competition laws, and in tort.
FEDERAL JURISDICTIONAL AREAS 33.1. Article 1, § 8, Clause 17 of the United States Constitution provides the authority to Congress to exercise exclusive jurisdiction over areas and structures used for military purposes (Federal Enclaves). Thus, Telecommunications Services to such Federal Enclaves are not subject to the jurisdiction of the Commission. The Parties agree that Services provided within Federal Enclaves are not within the scope of this Agreement. To the extent Sprint has contracts with federal entities that limit or prohibit the ability of CLEC to provide resale or UNEs such contract will govern Telecommunications Services on such Federal Enclave. If the contract with the federal entity provides for the resale or provision of UNEs to provide service on the Federal Enclave, Sprint will provide CLEC with the information regarding the provision of service on the Federal Enclave.
