Title, Management and Disposition of REO Property In the event that title to any Mortgaged Property is acquired in foreclosure or by deed in lieu of foreclosure, the deed or certificate of sale shall be taken, pursuant to a limited power of attorney in the form attached hereto as Exhibit H, in the name of the Trustee or its nominee (which in no event shall be the Special Servicer) in trust for the benefit of the Certificateholders, or in the event the Trustee is not authorized or permitted to hold title to real property in the state where the REO Property is located, or would be adversely affected under the “doing business” or tax laws of such state by so holding title, the deed or certificate of sale shall be taken in the name of such Person or Persons as shall be consistent with an Opinion of Counsel obtained by the Special Servicer (with a copy delivered to the Trustee) from any attorney duly licensed to practice law in the state where the REO Property is located. Any such Opinion of Counsel will be deemed a Servicing Advance, reimbursable to the Special Servicer in accordance with Section 3.04. The Person or Persons holding such title other than the Trustee shall acknowledge in writing that such title is being held as nominee for the Trustee. The Special Servicer shall manage, conserve, protect and operate each REO Property for the Trustee solely for the purpose of its prompt disposition and sale. The Special Servicer, either itself or through an agent selected by the Special Servicer, shall manage, conserve, protect and operate the REO Property in the same manner that it manages, conserves, protects and operates other foreclosed property for its own account, and in the same manner that similar property in the same locality as the REO Property is managed. The Special Servicer shall attempt to sell the same (and may temporarily rent the same for a period not greater than one year, except as otherwise provided below) on such terms and conditions as the Special Servicer deems to be in the best interest of the Trustee and the Certificateholders. In the event that the Trust Fund acquires any REO Property in connection with a default or imminent default on a Transferred Mortgage Loan, the Special Servicer shall dispose of such REO Property not later than the end of the third taxable year after the year of its acquisition by the Trust Fund unless the Special Servicer has applied for and received a grant of extension from the Internal Revenue Service (and provide a copy of the same to the Master Servicer and the Trustee) to the effect that, under the REMIC Provisions and any relevant proposed legislation and under applicable state law, the applicable Trust REMIC may hold REO Property for a longer period without adversely affecting the REMIC status of such REMIC or causing the imposition of a federal or state tax upon such REMIC and has notified the Master Servicer and the Trustee of such extension by providing a copy of the application and the grant of such extension to the Trustee and the Master Servicer. If the Special Servicer has received such an extension (and provided a copy of the same to the Master Servicer and the Trustee), then the Special Servicer shall continue to attempt to sell the REO Property for its fair market value for such period longer than three years as such extension permits (the “Extended Period”). If the Special Servicer has not received such an extension and the Special Servicer is unable to sell the REO Property within the period ending three months before the end of such third taxable year after its acquisition by the Trust Fund or if the Special Servicer has received such an extension, and the Special Servicer is unable to sell the REO Property within the period ending three months before the close of the Extended Period, the Special Servicer shall, before the end of the three-year period or the Extended Period, as applicable, (i) purchase such REO Property at a price equal to the REO Property’s fair market value or (ii) auction the REO Property to the highest bidder (which may be the Special Servicer) in an auction reasonably designed to produce a fair price prior to the expiration of the three-year period or the Extended Period, as the case may be. The Trustee shall sign any document reasonably requested by, and at the expense of, the Special Servicer, or take any other action reasonably requested by the Special Servicer which would enable the Special Servicer, on behalf of the Trust Fund, to request such grant of extension. In all cases, the disposition of REO Property shall be carried out by the Special Servicer at such price, and upon such terms and conditions, as the Servicer deems to be in the best interests of the Trust Fund. Notwithstanding any other provisions of this Agreement, no REO Property acquired by the Trust Fund shall be rented (or allowed to continue to be rented) or otherwise used by or on behalf of the Trust Fund in such a manner or pursuant to any terms that would: (i) cause such REO Property to fail to qualify as “foreclosure property” within the meaning of Section 860G(a)(8) of the Code; or (ii) subject any Trust REMIC to the imposition of any federal income taxes on the income earned from such REO Property, including any taxes imposed by reason of Sections 860F or 860G(c) of the Code, unless the Special Servicer has agreed to indemnify and hold harmless the Trust Fund with respect to the imposition of any such taxes. The Special Servicer shall also maintain on each REO Property fire and hazard insurance with extended coverage in amount which is at least equal to the maximum insurable value of the improvements which are a part of such property, liability insurance and, to the extent required and available under the Flood Disaster Protection Act of 1973, as amended, flood insurance in the amount required above. The proceeds of sale of the REO Property shall be promptly deposited in the Custodial Account. As soon as practical thereafter the expenses of such sale shall be paid and the Special Servicer shall reimburse itself for any related unreimbursed Servicing Advances, unpaid Servicing Fees, unreimbursed Monthly Advances made pursuant to this Section or Section 4.03 or the REO Disposition Fee. The Special Servicer shall make advances of all funds necessary for the proper operation, management and maintenance of the REO Property, including the cost of maintaining any hazard insurance pursuant to Section 3.10, such advances to be reimbursed from the disposition or liquidation proceeds of the REO Property. The Special Servicer shall make monthly distributions on each Remittance Date to the Master Servicer of the net cash flow from the REO Property (which shall equal the revenues from such REO Property net of the expenses described in this Section 3.17 and of any reserves reasonably required from time to time to be maintained to satisfy anticipated liabilities for such expenses).
Lessee as Prior Owner/Occupant The warranties made by Lessor in Paragraph 2 shall be of no force or effect if immediately prior to the Start Date Lessee was the owner or occupant of the Premises. In such event, Lessee shall be responsible for any necessary corrective work.
Title, Management and Disposition of Any REO Mortgage Loan The Master Servicer shall enforce the obligations of the applicable Servicer to administer each REO Mortgage Loan at all times so that each REO Mortgage Loan qualifies as "foreclosure property" under the REMIC Provisions and that it does not earn any "net income from foreclosure property" which is subject to tax under the REMIC Provisions. In the event that a Servicer is unable to dispose of any REO Mortgage Loan within the period mandated by each of the Servicing Agreements, the Master Servicer shall monitor such Servicer to verify that such REO Mortgage Loan is auctioned to the highest bidder within the period so specified. In the event of any such sale of a REO Mortgage Loan, the Custodian shall, at the written request of the Master Servicer and upon being supported with appropriate forms therefor, within five Business Days of the deposit by the Master Servicer of the proceeds of such sale or auction into the Certificate Account, release or cause to be released to the entity identified by the Master Servicer the related Owner Mortgage Loan File, Retained Mortgage Loan File, if applicable, and Servicer Mortgage Loan File and shall execute and deliver such instruments of transfer or assignment, in each case without recourse, as shall be necessary to vest in the auction purchaser title to the REO Mortgage Loan and the Custodian shall have no further responsibility with regard to such Owner Mortgage Loan File, Retained Mortgage Loan File, if applicable, or Servicer Mortgage Loan File. Neither the Trustee, the Master Servicer nor any Servicer, acting on behalf of the Trust Estate, shall provide financing from the Trust Estate to any purchaser of an REO Mortgage Loan.
Cooperative Property The real property and improvements owned by the Cooperative Corporation, that includes the allocation of individual dwelling units to the holders of the Cooperative Shares of the Cooperative Corporation.
Reports of Foreclosures and Abandonment of Mortgaged Property The Master Servicer or the Subservicers shall file information returns with respect to the receipt of mortgage interests received in a trade or business, the reports of foreclosures and abandonments of any Mortgaged Property and the information returns relating to cancellation of indebtedness income with respect to any Mortgaged Property required by Sections 6050H, 6050J and 6050P, respectively, of the Code, and deliver to the Trustee an Officers' Certificate on or before March 31 of each year stating that such reports have been filed. Such reports shall be in form and substance sufficient to meet the reporting requirements imposed by Sections 6050H, 6050J and 6050P of the Code.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Management of REO Property (a) Prior to the acquisition by it of title to a Mortgaged Property (other than a Mortgaged Property that secures an Outside Serviced Loan Combination), the Special Servicer shall review the operation of such Mortgaged Property and determine the nature of the income that would be derived from such property if it were acquired by the Trust Fund. If the Special Servicer determines from such review that:
(i) None of the income from Directly Operating such Mortgaged Property would be subject to tax as "net income from foreclosure property" within the meaning of the REMIC Provisions or would be subject to the tax imposed on "prohibited transactions" under Section 860F of the Code (either such tax referred to herein as an "REO Tax"), then such Mortgaged Property may be Directly Operated by the Special Servicer as REO Property;
(ii) Directly Operating such Mortgaged Property as REO Property could result in income from such property that would be subject to an REO Tax, but that a lease of such property to another party to operate such property, or the performance of some services by an Independent Contractor with respect to such property, or another method of operating such property would not result in income subject to an REO Tax, then the Special Servicer may (provided that in the good faith and reasonable judgment of the Special Servicer, it is commercially reasonable) acquire such Mortgaged Property as REO Property and so lease or operate such REO Property; or
(iii) It is reasonable to believe that Directly Operating such property as REO Property could result in income subject to an REO Tax and that no commercially reasonable means exists to operate such property as REO Property without the Trust Fund incurring or possibly incurring an REO Tax on income from such property, the Special Servicer shall deliver to the Tax Administrator, in writing, a proposed plan (the "Proposed Plan") to manage such property as REO Property. Such plan shall include potential sources of income, and, to the extent reasonably possible, estimates of the amount of income from each such source. Upon request of the Special Servicer, the Tax Administrator shall advise the Special Servicer of the Tax Administrator's federal income tax reporting position with respect to the various sources of income that the Trust Fund would derive under the Proposed Plan. After receiving the information described in the preceding sentence from the Tax Administrator, the Special Servicer shall implement the Proposed Plan (after acquiring the respective Mortgaged Property as REO Property), with any amendments required to be made thereto as a result of the Tax Administrator's tax reporting position. The Special Servicer's decision as to how each Administered REO Property shall be managed and operated shall be based on the Servicing Standard and, further, based on the good faith and reasonable judgment of the Special Servicer as to which means would be in the best interest of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)), as a collective whole, by maximizing (to the extent commercially reasonable and consistent with Section 3.17(b)) the net after-tax REO Revenues received with respect to such property without materially impairing the Special Servicer's ability to promptly sell such property for a fair price. In connection with performing their respective duties under this Section 3.17(a), both the Special Servicer and the Tax Administrator may consult with counsel and tax accountants, the reasonable cost of which consultation shall be covered by, and be reimbursable as, a Servicing Advance to be made by the Special Servicer.
(b) If title to any Administered REO Property is acquired, the Special Servicer shall manage, conserve, protect and operate such REO Property for the benefit of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) solely for the purpose of its prompt disposition and sale in a manner that does not and will not: (i) cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code; or (ii) except as contemplated by Section 3.17(a), either result in the receipt by any REMIC Pool of any "income from non-permitted assets" within the meaning of Section 860F(a)(2)(B) of the Code or result in an Adverse REMIC Event or an Adverse Grantor Trust Event. Subject to the foregoing, however, the Special Servicer shall have full power and authority to do any and all things in connection therewith as are consistent with the Servicing Standard and, consistent therewith, shall withdraw from the related REO Account, to the extent of amounts on deposit therein with respect to any Administered REO Property, funds necessary for the proper operation, management, maintenance and disposition of such REO Property, including:
(i) all insurance premiums due and payable in respect of such REO Property;
(ii) all real estate taxes and assessments in respect of such REO Property that may result in the imposition of a lien thereon;
(iii) any ground rents in respect of such REO Property; and
(iv) all costs and expenses necessary to maintain, lease, sell, protect, manage, operate and restore such REO Property. To the extent that amounts on deposit in the related REO Account in respect of any Administered REO Property are insufficient for the purposes set forth in the preceding sentence with respect to such REO Property, the Master Servicer shall, at the direction of the Special Servicer, make Servicing Advances in such amounts as are necessary for such purposes unless the Master Servicer determines, in accordance with the Servicing Standard, that such payment would be a Nonrecoverable Advance; provided, however, that the Master Servicer may make any such Servicing Advance without regard to recoverability if it is a necessary fee or expense incurred in connection with the defense or prosecution of legal proceedings.
(c) Without limiting the generality of the foregoing, the Special Servicer shall not, with respect to any Administered REO Property:
(i) enter into, renew or extend any New Lease with respect to such Administered REO Property, if the New Lease, by its terms would give rise to any income that does not constitute Rents from Real Property;
(ii) permit any amount to be received or accrued under any New Lease other than amounts that will constitute Rents from Real Property;
(iii) authorize or permit any construction on such Administered REO Property, other than the completion of a building or other improvement thereon, and then only if more than 10% of the construction of such building or other improvement was completed before default on the related Serviced Mortgage Loan became imminent, all within the meaning of Section 856(e)(4)(B) of the Code; or
(iv) Directly Operate, or allow any other Person, other than an Independent Contractor, to Directly Operate such Administered REO Property on any date more than 90 days after the related REO Acquisition; unless, in any such case, the Special Servicer has obtained an Opinion of Counsel (the cost of which shall be paid by the Master Servicer, at the direction of the Special Servicer, and shall be reimbursable as a Servicing Advance) to the effect that such action would not cause such Administered REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code at any time that it is held by a REMIC Pool, in which case the Special Servicer may take such actions as are specified in such Opinion of Counsel.
(d) The Special Servicer may contract with any Independent Contractor for the operation and management of any Administered REO Property; provided that:
(i) the terms and conditions of any such contract shall not be inconsistent herewith and shall reflect an agreement reached at arm's length;
(ii) the fees of such Independent Contractor (which shall be expenses of the Trust Fund and, in the case of any Administered REO Property that relates to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) shall be reasonable and customary in consideration of the nature and locality of such Administered REO Property;
(iii) except as permitted under Section 3.17(a), any such contract shall require, or shall be administered to require, that the Independent Contractor, in a timely manner, (A) pay out of related REO Revenues all costs and expenses incurred in connection with the operation and management of such Administered REO Property, including those listed in Section 3.17(b) above, and (B) except to the extent that such revenues are derived from any services rendered by the Independent Contractor to tenants of such Administered REO Property that are not customarily furnished or rendered in connection with the rental of real property (within the meaning of Section 1.856-4(b)(5) of the Treasury regulations or any successor provision), remit all related revenues collected (net of its fees and such costs and expenses) to the Special Servicer upon receipt;
(iv) none of the provisions of this Section 3.17(d) relating to any such contract or to actions taken through any such Independent Contractor shall be deemed to relieve the Special Servicer of any of its duties and obligations hereunder with respect to the operation and management of such Administered REO Property; and
(v) the Special Servicer shall be obligated with respect thereto to the same extent as if it alone were performing all duties and obligations in connection with the operation and management of such Administered REO Property. The Special Servicer shall be entitled to enter into any agreement with any Independent Contractor performing services for it related to its duties and obligations under Section 3.16 and this Section 3.17 for indemnification of the Special Servicer by any such Independent Contractor, and nothing in this Agreement shall be deemed to limit or modify such indemnification. No agreement entered into pursuant to this Section 3.17(d) shall be deemed a Sub-Servicing Agreement for purposes of Section 3.22.
(e) Notwithstanding anything to the contrary, this Section 3.17 shall not apply to any Outside Administered REO Property.
Reports of Foreclosures and Abandonments of Mortgaged Property Following the foreclosure sale or abandonment of any Mortgaged Property, the Servicer shall report such foreclosure or abandonment as required pursuant to Section 6050J of the Code.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
