Final Project Report Prepare a Final Project Report that addresses, to the extent feasible, comments made by the Grant Manager on the Draft Final Project Report. Submit one (1) reproducible master and an electronic copy of the final. Upload an electronic copy of the final report in pdf format to the FAAST system.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Construction Cost Estimate At 50% completion of the contract documents, the design team will present and submit copies of the project plans and manual. The Construction Administrator will prepare and issue the fourth of five construction cost estimates. The estimate shall be derived from actual takeoffs, subcontractor and vendor input, and material and labor cost data. All quantitative systems information shall be provided in detail.
Preliminary Cost Estimates The Engineer shall develop a preliminary cost estimate using the Average Low Bid Unit Price. The Engineer shall estimate the total project cost including preliminary engineering, final engineering, right-of-way (ROW) acquisition, environmental compliance and mitigation, construction, utility relocation, and construction engineering inspection (CEI).
Overall Project Schedule The Construction Progress Schedule that is approved by the Owner.
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Project Construction Budget The project construction cost allowance specifically stated in writing as the ‘revised’ or ‘current’ ‘Project Construction Budget’ by the Trustees at each applicable phase of plan development.
