Vendor’s Warranties CONTRACTOR irrevocably appoints the LEA its agent and attorney-in-fact during the term of this Agreement, so long as the LEA shall not be in default hereunder for the purpose of asserting from time to time whatever claims and rights which CONTRACTOR may have against the Vendor, including warranty claims with respect to the Accepted Buses, but for no other purpose whatsoever. The LEA’s sole remedy for the breach of a warranty shall be against the Vendor and not against CONTRACTOR, nor shall such matters have any effect whatsoever of this Agreement, including the LEA’s obligation to make timely Installment Payments hereunder. The LEA expressly acknowledges that CONTRACTOR makes, and has made, no representation or warranties whatsoever as to the existence or availability of such warranties from the Vendor.
Seller’s Warranties 10.1 Each of the Sellers warrants to the Buyers, in the terms of the Warranties at the date of this Agreement.
10.2 The Warranties contained in paragraphs 1 to 5, 6.3, 8.3, 10.1, 10.5, 11.1, 13, 17.2 and 18 of Schedule 3 are made of the date hereof and are repeated as of the Completion Date by the Sellers; all other Warranties are made exclusively as of the date hereof.
10.3 The Warranties are qualified by matters fairly disclosed in the Disclosure Letter. In addition to any specific matter disclosed or deemed to be disclosed in accordance with the Disclosure Letter, if and to the extent that the Buyers or any of the directors, officers, employees and/or professional advisers of the Buyers respectively its Affiliates, to the extent they were involved in the investigation of the Company and its business, the evaluation of the Transaction and negotiation of this Agreement, was aware or had notice at any time before the signature of the Agreement of any information relating to the subject matter of the Warranties that could reasonably be expected to put the Buyer on notice of such breach in light of the circumstances, then the Warranties shall be qualified by such information.
10.4 Following the execution of this Agreement but prior to the Completion Date (i) with regard to Warranties listed in Clause 10.2 above the Sellers shall, and (ii) with regard to all other Warranties the Sellers may supplement or amend the Disclosure Letter to reflect matters or circumstances which have arisen after the date hereof. No supplement or amendment to the Disclosure Letter shall be deemed to cure any breach of any Warranty made as of the date of this Agreement or as of the Completion Date, as the case may be. Absent fraud or willful concealment, no failure to supplement or amend the Disclosure Letter in accordance with this Clause 10.4 shall, by itself, constitute a basis for any Claim. Acceptance of any amendment or supplement to the Disclosure Letter shall be without prejudice to the rights of the Buyers to claim for any breach of Warranty made as at the date of this Agreement or as of the Completion Date, as the case may be.
10.5 Where a Warranty is qualified by the expression “so far as the Sellers are aware”, that Warranty shall be deemed to refer to the actual knowledge of the Sellers, the Other Participants, Ixxx Xxxxx, Ixxxx Xxxxxxx, Vxxxxxxxxx Gnasevich, Vxxxxxxx Xxxxxxxx, Vxxxxxxx Xxxxxxxxxx, Txxxxxx Chabunuk, Exxxxxxxx Xxxxxxxx or Julija Didan, not having made any specific inquiries thereto.
10.6 Each of the Warranties shall be construed as a separate and independent warranty and (except where this Agreement provides otherwise) shall not be limited or restricted in its scope by reference to or inference from any other term of another Warranty or this Agreement.
10.7 The Buyers, together with their Representatives, have conducted their own independent investigation of the business of the Company. In entering into this Agreement, the Parties acknowledge that the Buyers are relying on the Warranties set forth in Schedule 3 of this Agreement, and the Buyers.
10.7.1 acknowledge that none of the Sellers, the Company or any of their respective shareholders or Representatives makes or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any of the documents or other information provided or made available to the Buyers or any of its Representatives,
10.7.2 agree, to the fullest extent permitted by law, that none of the Sellers, the Company, any of their shareholders or Representatives shall have any liability or responsibility whatsoever to the Buyers or any of their Representatives on any basis based upon any information provided or made available, or statements made (including in materials furnished in the Data Room, in presentations by the Company’s management or otherwise), to the Buyers or any of their Representatives (or any omissions there from), except that the foregoing limitations shall not apply to any of the Sellers insofar as any such Seller makes the specific Warranties, set forth in Schedule 3 of this Agreement, subject always to the limitations and restrictions contained in Schedule 4.
Purchaser’s Warranties 7.1 The Purchaser hereby represents and warrants to the Seller and OTH as of the date of this Agreement that each of the warranties and representations in this Clause 7 is true and accurate in all respects and not misleading as at the date of this Agreement:
(i) The Purchaser is wholly owned and controlled ultimately by Xx Xx Xx-xxxxx and is a corporation duly organised, validly existing and in good standing under the laws of the British Virgin Islands.
(ii) The Purchaser is not in receivership or liquidation nor has it taken any step to enter liquidation, and no petition has been presented for winding up the Purchaser. There are no grounds on which a petition or application could be based for the winding up or appointment of a receiver of the Purchaser.
(iii) The Purchaser has the corporate power and authority to execute, deliver and perform its obligations under and consummate the transactions contemplated by each of the Transaction Documents to which it is a party and the other instruments and agreements to be executed and delivered by the Purchaser as contemplated hereby and thereby.
(iv) The entry into and performance of the Transaction Documents to which the Purchaser is a party will not constitute a breach by the Purchaser of or default under: (A) any provision of the organisational documents of the Purchaser; (B) any legally binding obligation or any material agreement or undertaking or the terms of any guarantee by which the Purchaser is bound; or (C) any Law applicable to the Purchaser;
7.2 Each of the Purchaser’s Warranties shall be separate and independent and (unless expressly provided otherwise) shall not be limited by reference to any other Purchaser’s Warranty or by anything in this Agreement.
7.3 The Purchaser acknowledges that the Seller and OTH are entering into this Agreement on the basis of and in reliance upon representations in the terms of the Purchaser’s Warranties.
Seller’s Warranties and Representations The matters set forth in this Section 11.1 constitute representations and warranties by Seller which are now and (subject to matters contained in any notice given pursuant to the next succeeding sentence) shall, in all material respects, at the Closing be true and correct. If Seller learns of, or has a reason to believe that any of the representations and warranties contained in this Article 11 may cease to be true and correct, Seller shall give prompt notice to Purchaser (which notice shall include copies of the instrument, correspondence, or document, if any, upon which Seller’s notice is based) and, in such event, Purchaser may terminate this Agreement, upon written notice to Seller, without recourse against Seller; provided, however; Seller cannot act voluntary in a manner which would cause a representation and warranty to become materially incorrect or inaccurate. As used in this Section 11.1, the phrase “to the extent of Seller’s actual knowledge” shall mean the actual current knowledge of Xxxx Xxxxxxx, with respect to water and sewage issues only, Xxxxxx Xxxxxx, Xxxx Xxxxxxxxx, Xxxx Xxxxxx, Xxx Xxxxxxxx and Xxxxx Xxxxxx whom Seller represents to be the representatives of Seller having the responsibility for the management and sale of the Golf Course and accordingly the individuals responsible for being informed of matters relevant to this Agreement. There shall be no duty imposed or implied to investigate, inspect, or audit any such matters, and there shall be no imputed or personal liability on the part of such individuals. To the extent Purchaser has or acquires actual knowledge prior to the Closing Date that these representations and warranties are inaccurate, untrue or incorrect in any way, Purchaser may proceed to Closing without reduction in the Purchase Price and without recourse against Seller for such misrepresentation, in which even such representation or warranties shall be deemed modified to reflect Purchaser’s actual knowledge.
Representations, Warranties and Covenants of Buyer Buyer represents, and warrants to and covenants with Seller as follows:
Buyer’s Warranties All representations and warranties by Buyer in this Agreement shall be true on and as of the closing date as though such representations and warranties were made on and as of that date.
Representations, Warranties and Covenants of the Pledgor The Pledgor hereby represents, warrants and covenants that:
(a) The Pledgor has full corporate power and authority to execute and deliver and perform its obligations under this Agreement and this Agreement is the Pledgor's valid and binding obligation, enforceable in accordance with its terms, except as such enforcement may be limited by (i) applicable bankruptcy, reorganization, insolvency, moratorium or other laws affecting creditors' rights generally, (ii) equitable rules or principles affecting the enforcement of obligations generally, whether at law or in equity, or (iii) the exercise of the discretionary powers of any court before which may be brought any proceeding seeking equitable remedies, including, without limitation, specific performance and injunctive relief.
(b) Pledgor represents and warrants that it is or will be before Commissioning (as such term is defined in the FPM Agreement) the owner of the Assets and has good and marketable title to the Assets, free and clear of all liens, security interests and other encumbrances, except for those in favor of the Pledgee.
(c) Pledgor will not sell, lease, transfer, exchange or otherwise dispose of the Assets, or any part thereof, without the prior written consent of Pledgee, and will not permit any lien, security interest or other encumbrance to attach to the Assets, or any part thereof, other than those in favor of the Pledgee or those permitted by Pledgee in writing.
(d) No approval, consent or other action by the stockholders and Pledgor or by any governmental authority, or by any other person or entity, is or will be necessary to permit the valid execution, delivery and performance by the Pledgor of this Agreement or any other instruments or agreements executed in connection herewith.
REPRESENTATIONS, WARRANTIES AND COVENANTS OF DEBTOR Debtor represents, warrants and covenants as of the date of this Agreement and as of the date of each Collateral Schedule that:
(a) Debtor’s exact legal name is as set forth in the preamble of this Agreement and Debtor is, and will remain, duly organized, existing and in good standing under the laws of the State set forth in the preamble of this Agreement, has its chief executive offices at the location specified in the preamble, and is, and will remain, duly qualified and licensed in every jurisdiction wherever necessary to carry on its business and operations;
(b) Debtor has adequate power and capacity to enter into, and to perform its obligations under this Agreement, each Note and any other documents evidencing, or given in connection with, any of the Indebtedness (all of the foregoing are called the “Debt Documents”);
(c) This Agreement and the other Debt Documents have been duly authorized, executed and delivered by Debtor and constitute legal, valid and binding agreements enforceable in accordance with their terms, except to the extent that the enforcement of remedies may be limited under applicable bankruptcy and insolvency laws;
(d) No approval, consent or withholding of objections is required from any governmental authority or instrumentality with respect to the entry into, or performance by Debtor of any of the Debt Documents, except any already obtained;
(e) The entry into, and performance by, Debtor of the Debt Documents will not (i) violate any of the organizational documents of Debtor or any judgment, order, law or regulation applicable to Debtor, or (ii) result in any breach of or constitute a default under any contract to which Debtor is a party, or result in the creation of any lien, claim or encumbrance on any of Debtor’s property (except for liens in favor of Secured Party) pursuant to any indenture, mortgage, deed of trust, bank loan, credit agreement, or other agreement or instrument to which Debtor is a party;
(f) There are no suits or proceedings pending in court or before any commission, board or other administrative agency against or affecting Debtor which could, in the aggregate, have a material adverse effect on Debtor, its business or operations, or its ability to perform its obligations under the Debt Documents, nor does Debtor have reason to believe that any such suits or proceedings are threatened;
(g) All financial statements delivered to Secured Party in connection with the Indebtedness have been prepared in accordance with generally accepted accounting principles, and since the date of the most recent financial statement, there has been no material adverse change in Debtors financial condition;
(h) The Collateral is not, and will not be, used by Debtor for personal, family or household purposes;
(i) The Collateral is, and will remain, in good condition and repair and Debtor will not be negligent in its care and use;
(j) Debtor is, and will remain, the sole and lawful owner, and in possession of, the Collateral, and has the sole right and lawful authority to grant the security interest described in this Agreement; and
(k) The Collateral is, and will remain, free and clear of all liens, claims and encumbrances of any kind whatsoever, except for (i) liens in favor of Secured Party, (ii) liens for taxes not yet due or for taxes being contested in good faith and which do not involve, in the judgment of Secured Party, any risk of the sale, forfeiture or loss of any of the Collateral, and (iii) inchoate materialmen’s, mechanic’s, repairmen’s and similar liens arising by operation of law in the normal course of business for amounts which are not delinquent (all of such liens are called “Permitted Liens”).
REPRESENTATIONS, WARRANTIES AND COVENANTS OF THE PLEDGORS Each Pledgor represents, warrants and covenants that:
(i) it is the legal, beneficial and record owner of, and has good and marketable title to, all Collateral pledged by such Pledgor hereunder and that it has sufficient interest in all Collateral pledged by such Pledgor hereunder in which a security interest is purported to be created hereunder for such security interest to attach (subject, in each case, to no pledge, lien, mortgage, hypothecation, security interest, charge, option, Adverse Claim or other encumbrance whatsoever, except the liens and security interests created by this Agreement and Permitted Liens (as defined in the Credit Agreements));
(ii) it has the corporate, limited partnership or limited liability company power and authority, as the case may be, to pledge all the Collateral pledged by it pursuant to this Agreement;
(iii) this Agreement has been duly authorized, executed and delivered by such Pledgor and constitutes a legal, valid and binding obligation of such Pledgor enforceable against such Pledgor in accordance with its terms, except to the extent that the enforceability hereof may be limited by applicable bankruptcy, insolvency, reorganization, moratorium or other similar laws generally affecting creditors’ rights and by equitable principles (regardless of whether enforcement is sought in equity or at law);
(iv) except to the extent already obtained or made, or, in the case of any filings or recordings of the Security Documents (as defined in the Credit Agreements) (other than the Collateral Vessel Mortgages) executed on or before the Restatement Effective Date, to be made within 10 days of the Restatement Effective Date, no consent of any other party (including, without limitation, any stockholder, partner, member or creditor of such Pledgor or any of its Subsidiaries (as defined in the Credit Agreements)) and no consent, license, permit, approval or authorization of, exemption by, notice or report to, or registration, filing or declaration with, any governmental authority is required to be obtained by such Pledgor in connection with (a) the execution, delivery or performance by such Pledgor of this Agreement, (b) the legality, validity, binding effect or enforceability of this Agreement, (c) the perfection or enforceability of the Pledgee’s security interest in the Collateral pledged by such Pledgor hereunder or (d) except for compliance with or as may be required by applicable securities laws, the exercise by the Pledgee of any of its rights or remedies provided herein;
(v) the execution, delivery and performance of this Agreement will not violate any provision of any applicable law or regulation or of any order, judgment, writ, award or decree of any court, arbitrator or governmental authority, U.S. or non-U.S., applicable to such Pledgor, or of the certificate or articles of incorporation, certificate of formation, operating agreement, limited liability company agreement, partnership agreement or by-laws of such Pledgor, as applicable, or of any securities issued by such Pledgor or any of its Subsidiaries (as defined in the Credit Agreements), or of any mortgage, deed of trust, indenture, lease, loan agreement, credit agreement or other material contract, agreement or instrument or undertaking to which such Pledgor or any of its Subsidiaries (as defined in the Credit Agreements) is a party or which purports to be binding upon such Pledgor or any of its Subsidiaries or upon any of their respective assets and will not result in the creation or imposition of (or the obligation to create or impose) any lien or encumbrance on any of the assets of such Pledgor or any of its Subsidiaries (as defined in the Credit Agreements) which are Credit Parties (as defined in the Credit Agreements), except as contemplated by this Agreement or the Credit Agreements; and
REPRESENTATIONS, WARRANTIES AND COVENANTS OF PURCHASER The Purchaser warrants and represents to, and covenants and agrees with, the Seller as follows:
