Engineer's Decisions Clause Samples

The "Engineer's Decisions" clause designates the engineer as the authority responsible for making determinations on technical matters, disputes, or ambiguities that arise during the execution of a project. In practice, this means that if there is disagreement between the contractor and the client regarding specifications, quality of work, or interpretation of the contract documents, the engineer's judgment will be sought and is typically binding unless otherwise specified. This clause ensures that technical issues are resolved efficiently by a qualified professional, thereby minimizing delays and maintaining project momentum.
Engineer's Decisions. 4.1 Except where otherwise specifically stated, the Engineer will decide contractual matters between the Employer and the Contractor in the role representing the Employer.
View SourceView Similar (73)
Engineer's Decisions. All claims of the owner or the contractor shall be presented to the Engineer for decision which shall be made in writing within a reasonable time. All decisions of the Engineer shall be final.
View SourceView Similar (17)
Engineer's Decisions a. The Engineer, if there is one, shall, within a reasonable time, make decisions on all claims of the Owner or Contractor and on all other matters relating to the execution and progress of the work or the interpretation of the Contract Documents. b. The decisions of the Engineer, if there is one, in matters relating to artistic effect, shall be final, if within the terms of the Contract Documents.
View SourceView Similar (2)
Engineer's Decisions. 6.1. Except where otherwise specifically stated, the Engineer will decide contractual matters between the Authority and the Contractor in the role representing the Authority. 6.2. The Engineer may delegate any of his duties and responsibilities to other people after notifying the Contractor and may cancel any delegation after notifying the Contractor.
View Source
Engineer's Decisions. 3.1 Except where otherwise specifically stated, the Engineer will decide contractual matters between the Employer and the Contractor in the role representing the Employer. However, if the Engineer is required under the rules and regulations and orders of the Employer to obtain prior approval of some other authorities for specific actions, he will so obtain the approval, before communicating his decision to the Contractor. 3.2 Except as expressly stated in the Contract, the Engineer shall not have any authority to relieve the Contractor of any of his obligations under the contract.
View Source

Related to Engineer's Decisions

  • Arbitration Decisions Unless otherwise agreed by the Parties, the arbitrator(s) shall render a decision within ninety (90) Calendar Days of appointment and shall notify the Parties in writing of such decision and the reasons therefor. The arbitrator(s) shall be authorized only to interpret and apply the provisions of this Agreement and shall have no power to modify or change any provision of this Agreement in any manner. The decision of the arbitrator(s) shall be final and binding upon the Parties, and judgment on the award may be entered in any court having jurisdiction. The decision of the arbitrator(s) may be appealed solely on the grounds that the conduct of the arbitrator(s), or the decision itself, violated the standards set forth in the Federal Arbitration Act or the Administrative Dispute Resolution Act. The final decision of the arbitrator must also be filed with FERC if it affects jurisdictional rates, terms and conditions of service, Attachment Facilities, System Upgrade Facilities, or System Deliverability Upgrades.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) (eff. Apr. 1, 2025, Section 544.0106, pursuant to House Bill 4611, Acts 2023, 88th Leg., R.S.) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.