Errors and Omissions All reports, files and other documents prepared and submitted by Contractor shall be complete and shall be carefully checked by the professional(s) identified by Contractor as project manager and key personnel attached hereto, prior to submission to the County. Contractor agrees that County review is discretionary and Contractor shall not assume that the County will discover errors and/or omissions. If the County discovers any errors or omissions prior to approving Contractor’s reports, files and other written documents, the reports, files or documents will be returned to Contractor for correction. Should the County or others discover errors or omissions in the reports, files or other written documents submitted by the Contractor after County approval thereof, County approval of Contractor’s reports, files or documents shall not be used as a defense by Contractor in any action between the County and Contractor, and the reports, files or documents will be returned to Contractor for correction.
Errors and Omissions, Professional Liability or Malpractice Insurance Contractor may be required to carry errors and omissions, professional liability or malpractice insurance. All policies shall remain in force through the life of this Contract and shall be payable on a "per occurrence" basis unless County specifically consents to a "claims made" basis. The insurer shall supply County adequate proof of insurance and/or a certificate of insurance evidencing coverages and limits prior to commencement of work. Should any of the required insurance policies in this Contract be cancelled or non-renewed, it is the Contractor’s duty to notify the County immediately upon receipt of the notice of cancellation or non-renewal. If Contractor does not carry a required insurance coverage and/or does not meet the required limits, the coverage limits and deductibles shall be set forth on a waiver, Exhibit C, attached hereto. Failure to provide and maintain the insurance required by this Contract will constitute a material breach of this Contract. In addition to any other available remedies, County may suspend payment to the Contractor for any services provided during any time that insurance was not in effect and until such time as the Contractor provides adequate evidence that Contractor has obtained the required coverage.
Errors and Warranty Contractor hereby warrants to District that the Work shall be performed in a professional and workmanlike manner consistent with the highest industry standards. Contractor shall perform any and all additional work necessary to correct errors in the work required under this Contract without undue delays or additional cost to District. Contractor shall correct or make arrangements to correct any breach of the warranty for the Work within ten (10) business days of notice from District of same.
Professional Liability (Errors and Omissions) For consultant contracts, insurance appropriate to Consultant’s profession, with limit no less than $1,000,000 per occurrence or claim, $2,000,000 aggregate. If Contractor maintains broader coverage and/or higher limits than the minimums shown above, City requires and shall be entitled to the broader coverage and/or the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to City.
Correction of Errors and Omissions; Other Liabilities (a) In the event any bookkeeping omissions or errors are discovered in preparing any pro forma statement or in completing the transfers and assumptions contemplated hereby, the parties hereto agree to correct such errors and omissions, it being understood that, as far as practicable, all adjustments will be made consistent with the judgments, methods, policies or accounting principles utilized by the Failed Bank in preparing and maintaining Accounting Records, except that adjustments made pursuant to this Section 8.2(a) are not intended to bring the Accounting Records of the Failed Bank into accordance with generally accepted accounting principles.
Professional Liability (Errors and Omissions) Insurance Limits shall not be less than the following:
Errors and Omissions Insurance Errors and Omissions Insurance to be maintained by the Servicer in accordance with Section 3.13.