Cost Overruns In the event that the costs and expenses incurred by Borrower in completing any work which is the subject of this Agreement exceed the respective amounts allocated by Lender for such items of expense, Borrower shall be responsible for the payment (from sources other than the Property Reserves) of such excess costs and expenses.
Project Costs The Project costs are true and accurate estimates of the costs necessary to complete the Improvements in a good and workmanlike manner according to the Plans and Specifications presented by Borrower to Lender, and Borrower shall take all steps necessary to prevent the actual cost of the Improvements from exceeding the Project costs.
Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.
Excess TI Costs Landlord shall have no obligation to bear any portion of the cost of any of the Tenant Improvements except to the extent of the TI Allowance. If at any time the remaining TI Costs under the Budget exceed the remaining unexpended TI Allowance, Tenant shall deposit with Landlord, as a condition precedent to Landlord’s obligation to complete the Tenant Improvements, 100% of the then current TI Cost in excess of the remaining TI Allowance (“Excess TI Costs”). If Tenant fails to deposit any Excess TI Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. The TI Allowance and Excess TI Costs are herein referred to as the “TI Fund.” Funds deposited by Tenant shall be the first disbursed to pay TI Costs. Notwithstanding anything to the contrary set forth in this Section 5(d), Tenant shall be fully and solely liable for TI Costs and the cost of Minor Variations in excess of the TI Allowance. If upon completion of the Tenant Improvements and the payment of all sums due in connection therewith there remains any undisbursed portion of the TI Fund, Tenant shall be entitled to such undisbursed TI Fund solely to the extent of any Excess TI Costs deposit Tenant has actually made with Landlord.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Reimbursable Costs Operator shall reimburse Contractor for the costs of material, equipment, work or services which are to be furnished by Operator as provided for herein but which for convenience are actually furnished by Contractor at Operator’s request, plus 5 percent for such cost of handling. When, at Operator’s request and with Contractor’s agreement, the Contractor furnishes or subcontracts for certain items or services which Operator is required herein to provide, for purposes of the indemnity and release provisions of this Contract, said items or services shall be deemed to be Operator furnished items or services. Any subcontractors so hired shall be deemed to be Operator’s contractor, and Operator shall not be relieved of any of its liabilities in connection therewith.
Attorneys’ Fees and Cost of Collection In the event any suit, action or arbitration is filed by either party against the other to interpret or enforce any of the Transaction Documents, the unsuccessful party to such action agrees to pay to the prevailing party all costs and expenses, including attorneys’ fees incurred therein, including the same with respect to an appeal. The “prevailing party” shall be the party in whose favor a judgment is entered, regardless of whether judgment is entered on all claims asserted by such party and regardless of the amount of the judgment; or where, due to the assertion of counterclaims, judgments are entered in favor of and against both parties, then the arbitrator shall determine the “prevailing party” by taking into account the relative dollar amounts of the judgments or, if the judgments involve nonmonetary relief, the relative importance and value of such relief. Nothing herein shall restrict or impair an arbitrator’s or a court’s power to award fees and expenses for frivolous or bad faith pleading. If (i) the Note is placed in the hands of an attorney for collection or enforcement prior to commencing arbitration or legal proceedings, or is collected or enforced through any arbitration or legal proceeding, or Investor otherwise takes action to collect amounts due under the Note or to enforce the provisions of the Note, or (ii) there occurs any bankruptcy, reorganization, receivership of Company or other proceedings affecting Company’s creditors’ rights and involving a claim under the Note; then Company shall pay the costs incurred by Investor for such collection, enforcement or action or in connection with such bankruptcy, reorganization, receivership or other proceeding, including, without limitation, attorneys’ fees, expenses, deposition costs, and disbursements.
Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.
LENDER'S EXPENDITURES If any action or proceeding is commenced that would materially affect Lender's interest in the Collateral or if Borrower fails to comply with any provision of this Agreement or any Related Documents, including but not limited to Borrower's failure to discharge or pay when due any amounts Borrower is required to discharge or pay under this Agreement or any Related Documents, Lender on Borrower's behalf may (but shall not be obligated to) take any action that Lender deems appropriate, including but not limited to discharging or paying all taxes, liens, security interests, encumbrances and other claims, at any time levied or placed on any Collateral and paying all costs for insuring, maintaining and preserving any Collateral. All such expenditures incurred or paid by Lender for such purposes will then bear interest at the rate charged under the Note from the date incurred or paid by Lender to the date of repayment by Borrower. All such expenses will become a part of the Indebtedness and, at Lender's option, will (A) be payable on demand; (B) be added to the balance of the Note and be apportioned among and be payable with any installment payments to become due during either (1) the term of any applicable insurance policy; or (2) the remaining term of the Note; or (C) be treated as a balloon payment which will be due and payable at the Note's maturity.
Development Costs With respect to activities prior to the Amendment Effective Date, each Party was to pay [*] of the total Direct Development Costs of a Product incurred in accordance with the Development Budget (as defined in the Original Agreement). Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, with respect to activities on and after the Amendment Effective Date, subject to Sections 3.1.2, Alimera will be solely responsible for, and shall pay one hundred percent (100%) of, all development costs of a Product, including Direct Development Costs. Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, (i) all payments owing by CDS hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by CDS (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), further including any penalties and interest which might have accrued with respect thereto, and further including all CDS payments deferred pursuant to that February 11, 2008 letter agreement sent by CDS and executed by CDS and Alimera regarding deferral of payments under the Original Agreement as of such date; (ii) all payments owing by Alimera hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by Alimera (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), and further including any penalties and interest which might have accrued with respect thereto; and (iii) subject to Sections 3.1.1 and 3.1.2, from and after the Amendment Effective Date, CDS will have no liability whatsoever hereunder for any past, present or future development costs, including Direct Development Costs (which includes those incurred before, on and after the Amendment Effective Date), and instead Alimera shall have sole liability therefor.
