TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
Conditions Precedent/Effectiveness Conditions This Amendment shall be effective upon the date of satisfaction of all of the following conditions precedent (the “Effective Date”): (a) Agent shall have received this Amendment fully executed by the Borrowers; (b) Agent shall have received updated schedule to the Loan Agreement, if any; (c) Agent shall have received a Guaranty, fully executed by the New Guarantor; (d) Agent shall have received a Pledge Agreement, fully executed by the New Guarantor; (e) Agent shall have received a copy of the Asset Transfer Agreement; (f) Agent shall have received a copy of the resolutions in form and substance reasonably satisfactory to Agent, of the board of directors or managers of New Guarantor, authorizing the execution, delivery and performance of this Amendment, the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, certified by the Secretary or an Assistant Secretary of New Guarantor; (g) Agent shall have received a certificate of the Secretary or an Assistant Secretary of New Guarantor as to the incumbency and signature of the officers of New Guarantor executing this Amendment the Guaranty, and any related agreements, instruments, or documents to which New Guarantor is a party, together with evidence of the incumbency of such Secretary or Assistant Secretary; (h) Agent shall have received an incumbency certificate for each Borrower identifying all authorized officers with specimen signatures, certified by the Secretary of such Borrower; (i) Agent shall have received copies of the bylaws and memorandum of association of New Guarantor, together with a certificate of good standing or equivalent certification in the jurisdiction of formation of New Guarantor; (j) Agent shall have received the results of UCC, tax lien, and judgment searches against New Guarantor; (k) Agent shall have received an opinion of counsel of New Guarantor; (l) Agent shall have received updated certificates of insurance naming New Guarantor as an additional insured with respect to liability insurance and lender loss payee with respect to property insurance; (m) Agent shall have received reasonably satisfactory evidence that the Guarantor Restructuring shall be consummated; and (n) No Default or Event of Default shall have occurred and be continuing under the Loan Agreement.
Effectiveness and Events Requiring Notice to the Underwriters The Company will use its best efforts to cause the Registration Statement to remain effective with a current prospectus until the later of nine (9) months from the Execution Date and the date on which the Warrants are no longer outstanding, and will notify the Underwriters and holders of the Warrants immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event during the period described in this Section 4.4 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such 9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. 9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims. 9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from: (a) unsettled liens, (b) faulty or defective Work appearing after Substantial Completion, (c) failure of the Work to comply with the requirements of the Contract Documents, or (d) terms of any special warranties required by the Contract Documents. 9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Effectiveness and Events Requiring Notice to the Representatives The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representatives immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.
Effectiveness and Events Requiring Notice to the Representative The Company will use its best efforts to cause the Registration Statement to remain effective and will notify the Representative immediately and confirm the notice in writing: (i) of the effectiveness of the Registration Statement and any amendment thereto; (ii) of the issuance by the Commission of any stop order suspending the effectiveness of the Registration Statement or any post-effective amendment thereto or preventing or suspending the use of any Preliminary Prospectus or the Prospectus or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the issuance by any foreign or state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iv) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (v) of the receipt of any comments or request for any additional information from the Commission; and (vi) of the happening of any event that, in the reasonable judgment of the Company, makes any statement of a material fact made in the Registration Statement or the Prospectus untrue or that requires the making of any changes in the Registration Statement or the Prospectus in order to make the statements therein, and in light of the circumstances under which they were made, not misleading. If the Commission or any foreign or state securities commission shall enter a stop order or suspend such qualification at any time, the Company will make every reasonable effort to obtain promptly the lifting of such order.
Effectiveness; Conditions Precedent The effectiveness of this Amendment and the amendments to the Fourth Amended Credit Agreement herein provided are subject to the satisfaction of the following conditions precedent: (a) the Administrative Agent shall have received each of the following documents or instruments in form and substance reasonably acceptable to the Administrative Agent: (i) counterparts of this Amendment, duly executed by each Borrower, each Guarantor, the Administrative Agent, each Lender under the Credit Agreement prior to giving effect to this Amendment that will continue as a Lender under the Credit Agreement after giving effect to this Amendment, and each Joining Lender; (ii) Domestic Term Loan Notes executed by WFS and Revolving Notes executed by WFS, World Fuel Services Europe, Ltd. and World Fuel Singapore in favor of each Joining Lender that has requested a Domestic Term Loan Note and a Revolving Note; (iii) such certificates of resolutions or other action, evidencing the authority and capacity (and if requested by the Administrative Agent, identity) of each Responsible Officer thereof authorized to act as a Responsible Officer in connection with this Amendment and the other Loan Documents to which such Loan Party is a party or is to be a party and good standing certificates (if applicable) of each Borrower and each Guarantor from its jurisdiction of organization; (iv) favorable opinions of counsel to the Borrowers, in each case addressed to the Lenders, as to such matters as the Administrative Agent or the Singapore Agent may reasonably request; and (v) a certificate signed by a Responsible Officer of WFS which shall include a list of the Guarantors and the Unrestricted Subsidiaries, if any, as of the Amendment No. 2 Effective Date and the aggregate book value of assets (including Equity Interests but excluding Investments that are eliminated in consolidation) represented by each such Guarantor and Unrestricted Subsidiary, as applicable, on an individual basis as of September 30, 2016 demonstrating compliance with the 70% Guaranty Threshold; (b) an upfront fee shall have been received for the account of each Lender, including any Joining Lender, party hereto, paid to the Administrative Agent for the account of such Lender, in accordance with that certain Joint Fee Letter dated as of October 12, 2016 (the “Joint Fee Letter”) among WFS, Bank of America, Xxxxxxx Lynch, Pierce, Xxxxxx & Xxxxx Incorporated, HSBC Bank USA, National Association, Xxxxx Fargo Bank, National Association and Xxxxx Fargo Securities, LLC; (c) an amendment fee shall have been received for the account of each Existing Lender party hereto, paid to the Administrative Agent for the account of such Existing Lender, in accordance with the Joint Fee Letter; and (d) all other fees and expenses payable to the Administrative Agent (unless waived by the Administrative Agent), the Joint Lead Arrangers, the Singapore Agent and the Lenders (including all fees owing pursuant to any Fee Letter and the reasonable fees and expenses of counsel to the Administrative Agent to the extent invoiced prior to the date hereof) shall have been paid in full (without prejudice to final settling of accounts for such fees and expenses).
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.