Excusable Delay Destruction of Aircraft Sample Clauses

Open Split View

Download

Share

Cite

Excusable Delay Destruction of Aircraft 

Sample 1

Save

Copy

Related to Excusable Delay Destruction of Aircraft

• Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

• Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

• DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion. b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination. c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease. d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.

• Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

• Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

• Damage or Destruction If any Property shall be damaged or destroyed, in whole or in part, by fire or other property hazard or casualty, Borrower shall give prompt notice thereof to Lender and one hundred (100%) percent of the net amount of all insurance proceeds received by Lender or Borrower as a result of such damage or destruction after deduction of reasonable costs and the expenses, if any, in collecting the same, shall be applied in reduction of the outstanding Principal Balance under the Note pertaining to the Damaged Property. Notwithstanding anything to the contrary set forth above, if a particular Property (a "DAMAGED PROPERTY") shall be damaged or destroyed, in whole or in part, by fire or other casualty, Lender shall, in accordance with the provisions of this Section hereinafter set forth, make the net amount of all insurance proceeds received by Lender pursuant to the provisions of this Agreement as a result of such damage or destruction after deduction of its reasonable costs and expenses, if any, in collecting the same (hereinafter referred to as the "NET PROCEEDS") available for the repair and restoration of the Damaged Property, provided that (i) no default shall have occurred and shall be continuing under the Loan Documents, (ii) Borrower shall commence the repair and restoration of the Damaged Property, as nearly as possible to the condition the Damaged Property was in immediately prior to such fire or other casualty, with such alterations as may be approved by Lender, as soon as reasonably practicable, and shall diligently pursue the same to satisfactory completion, (iii) Lender shall be satisfied that any operating deficits which will be incurred with respect to the Damaged Property as a result of the occurrence of any such fire or other casualty will be covered out of the Net Proceeds or by Borrower out-of-pocket or with the proceeds, if any, of business interruption or rental interruption insurance, (iv) Lender shall be satisfied that, within a reasonable period of time, not to exceed one hundred eighty (180) days following the completion of such repair and restoration of the Damaged Property, the gross cash flow and the net cash flow of the Damaged Property will be restored to a level sufficient to cover all carrying costs and operating expenses of the Damaged Property, (v) Lender shall be satisfied that the repair and restoration of the Damaged Property will be completed on or before the earlier to occur of (w) ninety (90) days prior to the Maturity Date, or (x) the date on which the business interruption insurance covered by such Borrower shall expire, (vi) Lender shall be satisfied that all of the terms, covenants and provisions of this Agreement and the other Loan Documents will continue to be complied with during and subsequent to the completion of such repair and restoration and (vii) Borrower and ARC IV shall execute and deliver to Lender a completion guaranty in form and substance satisfactory to Lender pursuant to the provisions of which Borrower and ARC IV shall jointly and severally guaranty to Lender the lien-free completion of the repair and restoration of the Damaged Property in accordance with the provisions of this paragraph. The Net Proceeds shall be held by Lender in an interest-bearing account, and until disbursed in accordance with the provisions of this paragraph, shall constitute additional security for the payment of the Debt. The Net Proceeds together with interest earned thereon, shall be disbursed by Lender to, or as directed by, Borrower from time to time during the course of the repair and restoration of the Damaged Property, upon receipt of evidence satisfactory to Lender (which evidence shall in each instance and to the full extent required by Lender include receipted bills, invoices, lien waivers and a continuation and date down of title to the Damaged Property in form satisfactory to Lender and issued by the title company insuring the lien of the Mortgage encumbering such Property or another title company satisfactory to Lender) that (i) all materials installed and work and labor performed (except to the extent that they are to be paid for out of the requested disbursement) in connection with the repair and restoration of the Damaged Property have been paid for in full, and (ii) there exist no notice of pendency, stop order, notice of intention to file mechanic's or materialman's lien, mechanic's or materialman's lien or other lien or encumbrance of any nature whatsoever on the Damaged Property arising out of the repair and restoration of the Damaged Property which have not either been fully bonded to the satisfaction of Lender and discharged of record or in the alternative fully insured over to the satisfaction of Lender by the title company insuring the lien of the Mortgage encumbering the Damaged Property. The repair and restoration of the Damaged Property shall be done and completed by Borrower in an expeditious and diligent fashion and in compliance with all applicable governmental laws, rules and regulations (including, without limitation, all applicable Environmental Requirements), and all plans and specifications required in connection with the repair and restoration of the Damaged Property shall be subject to review and acceptance in all respects by Lender and by the Consultant. If Lender fails to respond within ten (10) Business Days following a request and submissions of plans and specifications for approval, such plans and specification shall be deemed approved by Lender. Upon the occurrence of an Event of Default, Lender shall have the use of such plan and specifications and all permits, licenses and approvals required or obtained in connection with the repair and restoration of the Damaged Property. The identity of the contractors, subcontractors and materialmen engaged in the repair and restoration of the Damaged Property, as well as the contracts under which they have been engaged, shall be identified to Lender and Consultant, if any. All costs and expenses incurred by Lender in connection with making the Net Proceeds available for the repair and restoration of the Damaged Property including, without limitation, reasonable counsel fees and reasonable fees of the Consultant, shall be paid by Borrower. In no event shall Lender be obligated to make disbursements of the Net Proceeds in excess of an amount equal to the costs actually incurred from time to time for work in place as part of the repair and restoration of the Damaged Property,

• Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.

• Data Destruction When no longer needed, all County PHI or PI must be cleared, purged, or destroyed consistent with NIST Special Publication 800-88, Guidelines for Media Sanitization such that the PHI or PI cannot be retrieved.

• Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

• Return/Destruction of PHI 15.1 Business Associate in connection with the expiration or termination of the contract or grant shall return or destroy, at the discretion of the Covered Entity, all PHI received from Covered Entity or created or received by Business Associate on behalf of Covered Entity pursuant to this contract or grant that Business Associate still maintains in any form or medium (including electronic) within thirty (30) days after such expiration or termination. Business Associate shall not retain any copies of the PHI. Business Associate shall certify in writing for Covered Entity (1) when all PHI has been returned or destroyed and (2) that Business Associate does not continue to maintain any PHI. Business Associate is to provide this certification during this thirty (30) day period. 15.2 Business Associate shall provide to Covered Entity notification of any conditions that Business Associate believes make the return or destruction of PHI infeasible. If Covered Entity agrees that return or destruction is infeasible, Business Associate shall extend the protections of this Agreement to such PHI and limit further uses and disclosures of such PHI to those purposes that make the return or destruction infeasible for so long as Business Associate maintains such PHI. This shall also apply to all Agents and Subcontractors of Business Associate.