Purchase, Sale and Delivery (a) On the basis of the representations, warranties and covenants contained in this Agreement, and subject to its terms and conditions, the Issuers agree to issue and sell to the Initial Purchasers, and each Initial Purchaser agrees, severally and not jointly, to purchase from the Issuers, the principal amount of Notes set forth opposite the name of such Initial Purchaser on Exhibit A. The purchase price for the Notes will be $973.75 per $1,000 principal amount Note.
(b) Delivery of the Notes shall be made, against payment of the purchase price therefor, at the offices of Xxxxxx & Xxxxxxx, New York, New York or such other location as may be mutually acceptable. Such delivery and payment shall be made at 9:00 a.m., New York City time, on March 17, 1999 or at such other time as shall be agreed upon by the Initial Purchasers and the Issuers. The time and date of such delivery and payment are herein called the "Closing Date."
(c) On the Closing Date, one or more Notes in definitive global form, registered in the name of Cede & Co., as nominee of The Depository Trust Company ("DTC"), having an aggregate amount corresponding to the aggregate principal amount of the Notes (the "Global Note") sold pursuant to Exempt Resales to Eligible Purchasers shall be delivered by the Issuers to the Initial Purchasers (or as the Initial Purchasers direct), against payment by the Initial Purchasers of the purchase price therefor, by wire transfer of immediately available funds, to an account or accounts designated by the Issuers, provided that the Issuers shall give at least one business days' prior written notice to the Initial Purchasers of the information required to effect such wire transfer. The Global Note shall be made available to the Initial Purchasers for inspection not later than 9:30 a.m. on the business day immediately preceding the Closing Date.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
PURCHASE, SALE AND DELIVERY OF THE FIRM SHARES (a) On the basis of the representations, warranties and covenants herein contained, and subject to the conditions herein set forth, the Company agrees to sell to the Underwriters and each Underwriter agrees, severally and not jointly, to purchase, at a price of $ per share, the number of Firm Shares set forth opposite the name of each Underwriter in Schedule I hereof, subject to adjustments in accordance with Section 9 hereof.
(b) Payment for the Firm Shares to be sold hereunder is to be made in Federal (same day) funds against delivery of certificates therefor to the Representatives for the several accounts of the Underwriters. Such payment and delivery are to be made through the facilities of The Depository Trust Company, New York, New York at 10:00 a.m., New York time, on the third business day after the date of this Agreement or at such other time and date not later than five business days thereafter as you and the Company shall agree upon, such time and date being herein referred to as the “Closing Date.” (As used herein, “business day” means a day on which the New York Stock Exchange is open for trading and on which banks in New York are open for business and are not permitted by law or executive order to be closed.)
(c) In addition, on the basis of the representations and warranties herein contained and subject to the terms and conditions herein set forth, the Company hereby grants an option to the several Underwriters to purchase the Option Shares at the price per share as set forth in the first paragraph of this Section 2. The option granted hereby may be exercised in whole or in part by giving written notice (i) at any time before the Closing Date and (ii) only once thereafter within 30 days after the date of this Agreement, by you, as Representatives of the several Underwriters, to the Company setting forth the number of Option Shares as to which the several Underwriters are exercising the option and the time and date at which such certificates are to be delivered. The time and date at which certificates for Option Shares are to be delivered shall be determined by the Representatives but shall not be earlier than three nor later than 10 full business days after the exercise of such option, nor in any event prior to the Closing Date (such time and date being herein referred to as the “Option Closing Date”). If the date of exercise of the option is three or more days before the Closing Date, the notice of exercise shall set the Closing Date as the Option Closing Date. The number of Option Shares to be purchased by each Underwriter shall be in the same proportion to the total number of Option Shares being purchased as the number of Firm Shares being purchased by such Underwriter bears to the total number of Firm Shares, adjusted by you in such manner as to avoid fractional shares. The option with respect to the Option Shares granted hereunder may be exercised only to cover over-allotments in the sale of the Firm Shares by the Underwriters. You, as Representatives of the several Underwriters, may cancel such option at any time prior to its expiration by giving written notice of such cancellation to the Company. To the extent, if any, that the option is exercised, payment for the Option Shares shall be made on the Option Closing Date in Federal (same day funds) through the facilities of The Depository Trust Company in New York, New York drawn to the order of the Company.
Deemed Delivery Unless shown to have been received earlier, such notice, instruction or other instrument shall be deemed to have been delivered, in the case of personal delivery, at the time it is left at the premises of the party, in the case of a registered letter at the expiration of five (5) business days after posting and, in the case of fax or electronic means, immediately on dispatch; provided that, if any document is sent by fax or electronic means outside normal business hours, it shall be deemed to have been received at the next time after delivery when normal business hours commence. Evidence that the notice, instruction, or other instrument was properly addressed, stamped, and put into the post shall be conclusive evidence of posting. In proving the service of notice sent by fax or electronic means it shall be sufficient to prove that the fax or electronic communication was properly transmitted.
Purchase Sale and Delivery of the Offered Shares (a) The Company agrees to issue and sell to the several Underwriters the Firm Offered Shares upon the terms herein set forth. On the basis of the representations, warranties, and agreements herein contained, and upon the terms but subject to the conditions herein set forth, the Underwriters agree, severally and not jointly, to purchase from the Company the respective number of Firm Offered Shares set forth opposite their names on Schedule A (the “List of the Underwriters”) attached hereto. The purchase price per Firm Offered Share to be paid by the several Underwriters to the Company shall be $[ ] per share (the “Purchase Price”).
(b) The Company shall deliver the Firm Offered Shares to be purchased by the Underwriters through the facilities of The Depository Trust Company (“DTC”) against payment of the Purchase Price therefor in Federal (same day) funds by official bank check or checks or wire transfer drawn to the order of the Company and payment therefor at the offices of [ ], [ ], [ ], [ ] [ ] (or such other place as may be agreed to by the Company and the Representative) at [10:00] a.m. New York City time, on [ ], 20[ ], or such other time and date not later than [10:00] a.m. New York City time, not later than seven full business days thereafter as the Representative shall designate by notice to the Company (the time and date of such closing are called the “First Closing Date”); provided, however, that if the Company has not made available to the Representative copies of the Prospectus within the time provided in Section 2(g) (the “Payment for the Offered Shares”) and Section 3(d) (the “Copies of Any Amendments and Supplements to the Prospectus”) hereof, the Representative may, in its sole discretion, postpone the First Closing Date until no later than two (2) full business days following delivery of copies of the Prospectus to the Representative. The Company hereby acknowledges that circumstances under which the Representative may provide notice to postpone the First Closing Date as originally scheduled include, but are in no way limited to, any determination by the Company or the Representative to recirculate to the public copies of an amended or supplemented Prospectus or a delay as contemplated by the provisions of Section 8 (the “Default of One or More of the Several Underwriters”).
(c) In addition, on the basis of the representations, warranties, and agreements herein contained, and upon the terms but subject to the conditions herein set forth, the Company hereby grants an option to the several Underwriters to purchase, severally and not jointly, up to an aggregate of [ ] Optional Offered Shares from the Company at the Purchase Price. The option granted hereunder is for use by the Underwriters solely in covering any over-allotments in connection with the sale and distribution of the Firm Offered Shares. The option granted hereunder may be exercised at any time (but not more than once) upon notice by the Representative to which notice may be given at any time within thirty (30) days from the date of this Agreement. Such notice shall set forth (i) the aggregate number of Optional Offered Shares as to which the Underwriters are exercising the option, (ii) the names and denominations in which the Optional Offered Shares are to be registered, and (iii) the time, date, and place at which the Optional Offered Shares will be delivered (which time and date may be simultaneous with, but not earlier than, the First Closing Date, and in such case the term “First Closing Date” shall refer to the time and date of delivery of the Firm Offered Shares and the Optional Offered Shares). Such time and date of delivery of the Optional Offered Shares, if subsequent to the First Closing Date, is called the “Second Closing Date” and shall be determined by the Representative and shall not be earlier than three (3) nor later than five (5) full business days after delivery of such notice of exercise. The First Closing Date and the Second Closing Date are each a “Closing Date” as referenced herein. If any Optional Offered Shares are to be purchased, (a) each Underwriter agrees, severally and not jointly, to purchase the number of Optional Offered Shares (subject to such adjustments to eliminate fractional shares as the Representative may determine) that bears the same proportion to the total number of Optional Offered Shares to be purchased as the number of Firm Offered Shares set forth on Schedule A (the “List of the Underwriters”) attached hereto opposite the name of such Underwriter bears to the total number of Firm Offered Shares and (b) the Company agrees, severally and not jointly, to sell the number of Optional Offered Shares (subject to such adjustments to eliminate fractional shares as the Representative may determine) that bears the same proportion to the total number of Optional Offered Shares to be sold as the number of Firm Offered Shares to be sold by the Company as set forth on Schedule A attached hereto opposite the name of such Underwriter bears to the total number of Firm Offered Shares. The Representative may cancel the option or excersie thereof at any time prior to its expiration by giving written notice of such cancellation to the Company.
(d) The Representative hereby advises the Company that the Underwriters intend to offer for sale to the public, as described in the Prospectus, their respective portions of the Offered Shares as soon after this Agreement has been executed as the Representative, in its sole judgment, has determined is advisable and practicable.
(e) Payment for the Offered Shares shall be made at the First Closing Date (and, if applicable, at the Second Closing Date) by wire transfer of immediately available funds to the order of the Company against delivery of such Offered Shares through the facilities of DTC. It is understood that the Representative has been authorized, for its own accounts and the accounts of the several Underwriters, to accept delivery of and receipt for, and make payment of the purchase price for, the Firm Offered Shares and any Optional Offered Shares that the Underwriters have agreed to purchase. [ ] individually and not as the Representative of the Underwriters, may (but shall not be obligated to) make payment for any Offered Shares to be purchased by any Underwriter whose funds shall not have been received by the Representative by the First Closing Date or the Second Closing Date, as the case may be, for the account of such Underwriter, but any such payment shall not relieve such Underwriter from any of its obligations under this Agreement.
(f) The Company shall deliver, or cause to be delivered, a credit representing the Firm Offered Shares to an account or accounts at DTC as designated by the Representative for the accounts of the Representative and the several Underwriters at the First Closing Date, against the irrevocable release of a wire transfer of immediately available funds for the amount of the purchase price therefor. The Company shall also deliver, or cause to be delivered, a credit representing the Optional Offered Shares that the Representative and the Underwriters have agreed to purchase to an account or accounts at DTC as designated by the Representative for the accounts of the Representative and the several Underwriters, at the Second Closing Date, against the irrevocable release of a wire transfer of immediately available funds for the amount of the purchase price therefor.
(g) Not later than 12:00 p.m. on the third business day following the date that the Offered Shares are first released by the Underwriters for sale to the public, the Company shall deliver or cause to be delivered, copies of the Prospectus in such quantities and at such places as the Representative shall request.
Delivery Delay The delivery of any certificate representing the Restricted Stock or other RS Property may be postponed by the Company for such period as may be required for it to comply with any applicable foreign, federal, state or provincial securities law, or any national securities exchange listing requirements and the Company is not obligated to issue or deliver any securities if, in the opinion of counsel for the Company, the issuance of such Shares shall constitute a violation by the Participant or the Company of any provisions of any applicable foreign, federal, state or provincial law or of any regulations of any governmental authority or any national securities exchange.
Delayed Delivery (a) No adjustment shall be made and the CONTRACT PRICE shall remain unchanged for the first thirty (30) days of the delay in delivery of the VESSEL ending as of 12 o'clock midnight Korean Standard Time on the thirtieth (30th) day of delay beyond the DELIVERY DATE calculated as provided in Article VII.1. hereof.
(b) If delivery of the VESSEL is delayed more than thirty (30) days beyond the DELIVERY DATE then, in such event, beginning at midnight of the thirtieth (30th) day after such due date, the CONTRACT PRICE of the VESSEL shall be reduced by U.S. Dollars Twenty Three Thousand (US$ 23,000) for each full day of delay. However, unless the parties agree otherwise, the total amount of deduction from the CONTRACT PRICE shall not exceed the amount due to cover the delay of one hundred and eighty (180) days after thirty (30) days of the delay in delivery of the VESSEL at the rate of deduction as specified hereinabove.
(c) But, if the delay in delivery of the VESSEL continues for a period of more than two hundred and ten (210) days beyond the DELIVERY DATE then, in such event, and after such period has expired, the BUYER may, at its option, rescind or cancel this CONTRACT, by serving upon the BUILDER a notice of cancellation by email or facsimile to be confirmed by a registered letter via airmail directed to the BUILDER at the address given in this CONTRACT. Such cancellation shall be effective as of the date the notice thereof is received by the BUILDER. If the BUYER has not served the notice of cancellation after the aforementioned two hundred and ten (210) days delay in delivery, the BUILDER may demand the BUYER to make an election in accordance with Article VIII.3. hereof.
(d) For the purpose of this Article, the delivery of the VESSEL shall be deemed to be delayed when and if the VESSEL, after taking into full account extension of the DELIVERY DATE or permissible delays as specifically provided in Articles V, VI, VIII, XI or elsewhere in this CONTRACT, is delivered beyond the date upon which delivery would then be due under the terms of this CONTRACT.
Purchase and Delivery Payment for the Firm Offered Securities shall be made to the Company in Federal or other funds immediately available in New York City at the closing time and place set forth in Schedule I hereto, or at such other time on the same or such other date, not later than the fifth business day thereafter, as may be designated by you in writing. The time and date of such payment are hereinafter referred to as the “Closing Date.” Payment for any Additional Offered Securities shall be made to the Company in Federal or other funds immediately available in New York City at the closing place referred to above on such date of your determination (which may be the same as the Closing Date but shall in no event be earlier than the Closing Date nor later than ten business days after the giving of the notice hereinafter referred to) as shall be designated in a written notice from you to the Company, on behalf of the Underwriters, to purchase a number, specified in said notice, of Additional Offered Securities, or on such other date as shall be designated in writing by you. In any event, such payment date shall be not later than __________, 20__. The time and date of such payment are hereinafter referred to as the “Option Closing Date.” The notice of the determination to exercise the option to purchase Additional Offered Securities and of the Option Closing Date may be given at any time within 30 days after the date of this Agreement. Payment for the Firm Offered Securities or any Additional Offered Securities shall be made against delivery to you on the Closing Date or the Option Closing Date, as the case may be, for the respective accounts of the several Underwriters, of the Firm Offered Securities or any Additional Capital Securities, as the case may be, registered in such names and in such denominations as you shall request in writing not later than one full business day prior to the Closing Date or the Option Closing Date, as the case may be, with any transfer taxes payable in connection with the transfer of the Firm Offered Securities or any Additional Offered Securities, as the case may be, to the Underwriters duly paid.
Notice and Delivery Any notice mailed to you will be deemed delivered and received by you, five days after the postmark date. This fifth day following the postmark is the receipt date. Notices will be mailed to the last address we have in our records. You are responsible for ensuring that we have your proper mailing address. Upon your consent, we may provide you with notice in a delivery format other than by mail. Such formats may include various electronic deliveries. Any notice, including terminations, change in personal information, or contributions mailed to us will be deemed delivered when actually received by us based on our ordinary business practices. All notices must be in writing unless our policies and procedures provide for oral notices.
Purchase Sale and Delivery of the Offered Securities Unless otherwise specified in the Underwriting Agreement, payment for the Offered Securities shall be made by certified or official bank check or checks payable to the order of the Depositor in immediately available or next day funds, at the time and place set forth in the Underwriting Agreement, upon delivery to the Representative for the respective accounts of the several Underwriters of the Offered Securities registered in definitive form and in such names and in such denominations as the Representative shall request in writing not less than five full business days prior to the date of delivery. The time and date of such payment and delivery with respect to the Offered Securities are herein referred to as the "Closing Date".
