Express Termination Clause and Suspension of the Service
Express Termination Clause and Suspension of the Service Sample Clauses
Related to Express Termination Clause and Suspension of the Service
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms. 18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other. 18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1. 18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate. 18.5 Either party may terminate this Agreement immediately, if the other party: (a) commits an irremediable breach; or (b) is subject to a change of control or chooses to discontinue its business; or (c) if the other party has a lack of funding or becomes or is deemed insolvent; or (d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more. 18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you. 18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy. 18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data. 18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you. 18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due. 18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement. 18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
Suspension; Termination If Borrower voluntarily suspends its business or, the partnership is dissolved or terminated, other than a technical termination of the partnership for tax purposes.
Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.
Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3. 9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party: (a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach. (b) Becomes insolvent or admits its inability to pay its debts generally as they become due. (c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing. (d) Is dissolved or liquidated or takes any corporate action for such purpose. (e) Makes a general assignment for the benefit of creditors. (f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business. 9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”): (a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment; (b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days; (c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.
Term; Termination; Survival of Provisions The term of this Agreement shall commence on the date hereof and shall continue, unless earlier terminated pursuant to the provisions of this section, for twelve (12) months, automatically renewed thereafter for monthly periods unless either Party informs the other in writing thirty (30) days prior to the end of the current term of its intent to terminate this Agreement. This Agreement may be terminated prior to the end of the current term, by mutual written consent of the Parties hereto, or: a. by any Party, upon thirty (30) days’ prior written notice; and b. by either Co-Manager (with respect to such Co-Manager, but not to the other Co-Manager) in the event that Client fails to pay any amount due hereunder within thirty (30) days of that due date or otherwise breaches its obligations to such Co-Manager. Termination of this Agreement will not affect either Co-Manager’s right to receive continuing compensation with respect to investments made prior to such termination. It is understood and agreed that the provisions of this Agreement relating to the payment of fees and expenses, confidentiality, and indemnification shall survive any termination of this Agreement.
TERM, TERMINATION & SUSPENSION The Company may terminate this Agreement with You at any time for any reason, with or without cause. The Company specifically reserves the right to terminate this Agreement if You violate any of the terms outlined herein, including, but not limited to, violating the intellectual property rights of the Company or a third party, failing to comply with applicable laws or other legal obligations, and/or publishing or distributing illegal material. If You have registered for an account with Us, You may also terminate this Agreement at any time by contacting Us and requesting termination. At the termination of this Agreement, any provisions that would be expected to survive termination by their nature shall remain in full force and effect.
Termination of the Agreement In the event of failure by the participant to perform any of the obligations arising from the agreement, and regardless of the consequences provided for under the applicable law, the institution is legally entitled to terminate or cancel the agreement without any further legal formality where no action is taken by the participant within one month of receiving notification by registered letter. If the participant terminates the agreement before its agreement ends or if he/she fails to follow the agreement in accordance with the rules, he/she shall have to refund the amount of the grant already paid, except if agreed differently with the sending organisation. In case of termination by the participant due to "force majeure", i.e. an unforeseeable exceptional situation or event beyond the participant's control and not attributable to error or negligence on his/her part, the participant shall be entitled to receive at least the amount of the grant corresponding to the actual duration of the mobility period. Any remaining funds shall have to be refunded, except if agreed differently with the sending organisation.
