Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI. (b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
FDA As to each product subject to the jurisdiction of the U.S. Food and Drug Administration (“FDA”) under the Federal Food, Drug and Cosmetic Act, as amended, and the regulations thereunder (“FDCA”) that is manufactured, packaged, labeled, tested, distributed, sold, and/or marketed by the Company or any of its Subsidiaries (each such product, a “Pharmaceutical Product”), such Pharmaceutical Product is being manufactured, packaged, labeled, tested, distributed, sold and/or marketed by the Company in compliance with all applicable requirements under FDCA and similar laws, rules and regulations relating to registration, investigational use, premarket clearance, licensure, or application approval, good manufacturing practices, good laboratory practices, good clinical practices, product listing, quotas, labeling, advertising, record keeping and filing of reports, except where the failure to be in compliance would not have a Material Adverse Effect. There is no pending, completed or, to the Company's knowledge, threatened, action (including any lawsuit, arbitration, or legal or administrative or regulatory proceeding, charge, complaint, or investigation) against the Company or any of its Subsidiaries, and none of the Company or any of its Subsidiaries has received any notice, warning letter or other communication from the FDA or any other governmental entity, which (i) contests the premarket clearance, licensure, registration, or approval of, the uses of, the distribution of, the manufacturing or packaging of, the testing of, the sale of, or the labeling and promotion of any Pharmaceutical Product, (ii) withdraws its approval of, requests the recall, suspension, or seizure of, or withdraws or orders the withdrawal of advertising or sales promotional materials relating to, any Pharmaceutical Product, (iii) imposes a clinical hold on any clinical investigation by the Company or any of its Subsidiaries, (iv) enjoins production at any facility of the Company or any of its Subsidiaries, (v) enters or proposes to enter into a consent decree of permanent injunction with the Company or any of its Subsidiaries, or (vi) otherwise alleges any violation of any laws, rules or regulations by the Company or any of its Subsidiaries, and which, either individually or in the aggregate, would have a Material Adverse Effect. The properties, business and operations of the Company have been and are being conducted in all material respects in accordance with all applicable laws, rules and regulations of the FDA. The Company has not been informed by the FDA that the FDA will prohibit the marketing, sale, license or use in the United States of any product proposed to be developed, produced or marketed by the Company nor has the FDA expressed any concern as to approving or clearing for marketing any product being developed or proposed to be developed by the Company.
Random Drug Testing All employees covered by this Agreement shall be subject to random drug testing in accordance with Appendix D.
Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable. (b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
Alcohol and Drug Testing Employee agrees to comply with and submit to any Company program or policy for testing for alcohol abuse or use of drugs and, in the absence of such a program or policy, to submit to such testing as may be required by Company and administered in accordance with applicable law and regulations.
Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
Clinical Trials The studies, tests and preclinical and clinical trials conducted by or on behalf of, or sponsored by, the Company, or in which the Company has participated, that are described in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus, or the results of which are referred to in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus, were and, if still pending, are being conducted in all material respects in accordance with protocols, procedures and controls pursuant to, where applicable, accepted professional and scientific standards for products or product candidates comparable to those being developed by the Company and all applicable statutes, rules and regulations of the FDA, the EMEA, Health Canada and other comparable drug and medical device (including diagnostic product) regulatory agencies outside of the United States to which they are subject; the descriptions of the results of such studies, tests and trials contained in the Registration Statement, the Time of Sale Disclosure Package or the Prospectus do not contain any misstatement of a material fact or omit a material fact necessary to make such statements not misleading; the Company has no knowledge of any studies, tests or trials not described in the Disclosure Package and the Prospectus the results of which reasonably call into question in any material respect the results of the studies, tests and trials described in the Registration Statement, the Time of Sale Disclosure Package or Prospectus; and the Company has not received any notices or other correspondence from the FDA, EMEA, Health Canada or any other foreign, state or local governmental body exercising comparable authority or any Institutional Review Board or comparable authority requiring or threatening the termination, suspension or material modification of any studies, tests or preclinical or clinical trials conducted by or on behalf of, or sponsored by, the Company or in which the Company has participated, and, to the Company’s knowledge, there are no reasonable grounds for the same. Except as disclosed in the Registration Statement, the Time of Sale Disclosure Package and the Prospectus, there has not been any violation of law or regulation by the Company in its respective product development efforts, submissions or reports to any regulatory authority that could reasonably be expected to require investigation, corrective action or enforcement action.
