Term Commencement Date The term of this Agreement shall commence on , 2020 (the “Commencement Date”) and, unless earlier terminated in accordance with the terms of this Agreement, shall end on June 30, 2055 (the “Term”).
Term Commencement The term for each Service will commence on the Service Commencement Date indicated in the Notice of Service Commencement delivered by Exodus to Customer when Exodus begins providing each Service to Customer.
Extension Term The Term of the Lease is hereby extended for sixty (60) months and, therefore, the Term Expiration Date is hereby amended to mean January 14, 2023. The period commencing on January 15, 2018 (the “Extension Term Commencement Date”) and ending on the Term Expiration Date shall be referred to herein as the “Extension Term.”
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Extension Terms Sublessee shall have two (2) successive options (each, an “Extension Option”) to extend the Term for periods of five (5) years each (each, an “Extension Term”), the first of which Extension Term shall commence on the termination date of the Base Term, and the second of which shall commence on the day immediately following the expiration of the first Extension Term, said Extended Terms to be on the same terms and conditions as the Lease except that (i) the Lease shall contain no further options to extend after the expiration of the second Extension Term, and (ii) the Fixed Rental Rate applicable to each Extension Term shall be computed as set forth below and not be subject to annual adjustment as provided in the reference data. Sublessee shall provide written notice (“Sublessee’s Extension Notice”) to Sublessor of its determination to exercise each such Extension Option no later than twelve (12) months prior to the expiration of the then current Term (“Notice Date”). The Fixed Rental Rate for each Extension Term shall be 90% of the fair market rental rate (the “Extension Rental Rate”) for the Leased Premises, which is defined as the then prevailing fair market net rental rate for office and warehouse space at comparable property in the Portsmouth and Dover, NH markets assuming no adjustment thereto during the applicable Extension Term and no free rent period or tenant improvement allowances, excluding the value of any Alterations or other improvements made to the Premises that were paid for by Sublessee and taking into consideration factors such as (i) the percentage of the Building occupied by Sublessee, (ii) Sublessee’s obligation to pay Expenses as provided herein, and (iii) any other relevant factors either Sublessee or Sublessor wishes to bring to the attention of the other or to a real estate professional called upon to assist in the determination of the fair market rental rate. The Extension Rental Rate shall be determined as follows: in the event Sublessee timely exercises an Extension Option in accordance herewith, within ten (10) business days after Sublessor receives Sublessee’s Extension Notice, Sublessor shall notify Sublessee in writing of Sublessor’s good faith determination of the fair market rental rate (“Sublessor’s Extension Term Rental Notice”), which notice shall set forth in reasonable detail Sublessor’s determination of such fair market rental rate and shall provide separately, if Sublessor wishes, rent concessions and/or tenant improvement allowances that Sublessor may wish to offer, and the amount by which Sublessor’s estimate of the fair market rental rate would increase as a result of the granting of such concessions (the “Concession Rate Amount”) and shall set forth Sublessor’s determination of the expiration date of the Negotiation Period. Sublessee shall have ten (10) business days from the date of Sublessor’s Extension Term Rental Notice to either accept or dispute Sublessor’s determination of the fair market rental rate. In the event that Sublessee disputes Sublessor’s determination of the fair market rental rate, Sublessee shall so notify Sublessor and advise Sublessor of Sublessee’s determination of the fair market rental rate (which notice shall set forth in reasonable detail Sublessee’s determination of the fair market rental rate as well as concessions and improvement allowances it may be seeking, including an alternate Concession Rate Amount). If Sublessor and Sublessee cannot agree upon the Extension Rental Rate within sixty (60) days of the date of Sublessor’s Extension Term Rental Notice (the “Negotiation Period”), Sublessee, at Sublessee’s option, shall give Sublessor, within three (3) business days of the expiration of the Negotiation Period, one of the following written notices: (a) a written notice revoking Sublessee’s exercise of such Extension Option, or (b) a written notice stating that Sublessee wishes to submit the matter to arbitration as set forth below. If Sublessee does not provide either notice, the exercise of such Extension Option shall be deemed revoked. If option (b) is chosen, Sublessor and Sublessee shall simultaneously exchange, on the fifth (5th) business day following the expiration of the Negotiation Period, statements setting forth each such party’s final determination of the fair market rental rate (each, a “Statement of Rental Rate”), including any Concession Rate Amount (separately stated), together with such backup information as to such party’s determination of the fair market rental rate and/or any Concession Rate Amount as such party wishes to include (and, in the case of Sublessor, the fair market rental rate in such Statement of Rental Rate shall not be greater than that set forth in Sublessor’s Extension Term Rental Notice and, in the case of Sublessee, the fair market rental rate in such Statement of Rental Rate shall not be less than that set forth in Sublessee’s initial determination of the fair market rental rate provided in response to Sublessor’s Extension Term Rental Notice). If the higher of the two (2) determinations of the fair market rental rate is equal to or less than 110% of the lesser determination, then the Extension Rental Rate shall be the average of the two determinations. Otherwise, Sublessor and Sublessee shall mutually select a real estate professional with at least ten (10) years’ continuous experience in the business of appraising or marketing multi-tenant mix-use commercial office, warehouse and industrial buildings in the greater Portsmouth area (the “Valuation Expert”) to resolve the dispute as to the Extension Rental Rate. If Sublessor and Sublessee cannot agree upon the designation of the Valuation Expert within ten (10) business days of the exchange of the Statements of Rental Rate, the parties shall apply to the New Hampshire Chapter of the Appraisal Institute (the “NHAI”) for appointment of a qualified Valuation Expert as follows: (i) the NHAI shall provide Sublessor and Sublessee with a list of five qualified Valuation Experts; (ii) within five (5) business days after such list is produced, each of Sublessor and Sublessee shall notify NHAI and the other party of those proposed experts that are acceptable (and, if desired, ranking the same), each being entitled to strike up to two candidates; (iii) if one party fails to send back its selections, then NHAI shall appoint the number one ranked expert proposed by the other party; if both parties fail to send back their selections, NHAI shall appoint a Valuation Expert in its discretion; and if both parties timely return their selections, then the Valuation Expert will be proposed expert that is the highest ranked (on a combined basis) by the parties as determined by NHAI. The Valuation Expert appointed by NHAI shall be final and binding upon Sublessor and Sublessee. Within five (5) business days of the selection of the Valuation Expert, Sublessor and Sublessee shall each submit to the Valuation Expert a copy of its Statement of Rental Rate, together with any supporting material. The Valuation Expert shall not perform his own valuation, but rather, shall, within fifteen (15) business days after receipt of such submissions, select as the Extension Rental Rate the submission which the Valuation Expert concludes most closely and accurately reflects the fair market rental rate for the Leased Premises and the fair market rental rate set forth in that submission shall be the Extension Rental Rate for such Extension Term. The Valuation Expert shall give notice of his or her determination to Sublessor and Sublessee, and such decision shall be final and conclusively binding upon Sublessor and Sublessee. In addition, Sublessee shall be entitled to elect to take advantage of the concessions last offered by Sublessor and include the Concession Rate Amount in the Extension Rental Rate by notice to Sublessor given within thirty (30) days of the final determination by the Valuation Expert. Each party shall pay the fees and expenses of any real estate professional such party retains and such party’s counsel, if any, in connection with any proceeding under this paragraph, and the party whose determination of the fair market rental rate was determined by the Valuation Expert not to most accurately and closely reflect the fair market rental rate of the Leased Premises shall pay the fees and expenses of the Valuation Expert. Sublessor and Sublessee shall execute an amendment to this Lease within thirty (30) days after the determination of the Extension Rental Rate (in accordance with the procedure set forth above) for the applicable Extension Term, which amendment shall set forth the Extension Term, the Extension Rental Rate, and all other terms and conditions for such Extension Term; provided, however, any failure to execute such amendment shall not affect such Extension Term or any terms or conditions for Sublessee’s leasing of the Premises for the applicable Extension Term.
Extended Term Tenant shall have the option to extend the Term for two (2) consecutive five (5) year periods (the "FIRST EXTENDED TERM" and "SECOND EXTENDED TERM", respectively) on all the terms and conditions contained in this Lease including, without limitation, continuation of the adjustment of the Base Rent on an annual basis as provided in Section 3.3 below (provided only that upon commencement of the First Extended Term the only remaining option to extend the Term shall be the Second Extended Term and upon exercise of the option with respect to the Second Extended Term, no further right to extend the Term shall exist). Tenant shall deliver, if at all, written notice of its exercise of the option ("OPTION NOTICE") to Landlord at least six (6) months but not more than one (1) year before the expiration of the Term or First Extended Term, as the case may be. In the event Tenant fails to deliver the applicable Option Notice within the time allowed, Landlord shall deliver written notice to Tenant of Tenant's failure to deliver the Option Notice, and Tenant shall then have thirty (30) days from receipt of such notice within which to deliver the Option Notice, if at all, to Landlord. In the event (and only in the event) that, Tenant fails to deliver an Option Notice to Landlord within such thirty (30) days, Tenant shall be considered to have elected not to extend the Term of this Lease and thereafter, Tenant shall have no further right to extend the Term of this Lease. References in this Lease to the "Term" shall include the initial Term of fifteen (15) years and shall, in addition, include the First Extended Term and the Second Extended Term, if applicable.
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Commencement Date Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
Extension Period Any extension hereof shall be subject to the provisions of Article III hereof.
