Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Room Condition The university agrees to provide and the resident agrees to maintain the assigned room and all public areas in and around the immediate building(s) accessible to the resident in a clean, safe and sanitary condition. Upon termination of this agreement, the student should leave the assigned room, its furnishings, and its equipment in as good an order and condition as the same were upon commencement of the student’s occupancy, ordinary wear and tear excepted. University staff will complete an inventory of furnishings and an assessment of damages; charges will be assessed to the responsible individual(s). Personal property left in a room following the termination of occupancy will be deemed abandoned. Students will be charged for the removal of such property.
Inspection Testing Authorization and Right of Access 2.1 Equipment Testing and Inspection 2.2 Authorization Required Prior to Parallel Operation
Failure of Conditions If the Conditions Precedent shall not have been satisfied or waived by February 27, 2015, either party may terminate this Lease and the Transfer Agreement by written notice of termination (the “Termination Notice”) delivered to the other party by February 27, 2015 (the “Failure of Conditions Termination Date”). Upon termination of this Lease under the terms of this Section 2, neither party hereto shall have any further claims or obligations under this Lease or the Transfer Agreement, except those obligations that expressly survive termination. Notwithstanding any provision of this Section 2.3 to the contrary, if the parties are unable to agree upon the initial Deferred Maintenance Items (as that term is defined in Section 9.2(c)(ii) below for the River Valley Facility to be included on Exhibit “E”, the sole remedy of the parties shall be to exclude the River Valley Facility from the Portfolio.
Stipulated Penalties for Failure to Comply with Certain Obligations As a contractual remedy, Xxxxxx and OIG hereby agree that failure to comply with certain obligations as set forth in this CIA may lead to the imposition of the following monetary penalties (hereinafter referred to as “Stipulated Penalties”) in accordance with the following provisions.
Abuse, Neglect, Exploitation Grantee will;
Failure to Supply Workmen or Materials or to Prosecute the Work A Notice of Non-Compliant Work may be issued for failure of the Contractor to supply enough workers or enough materials or proper materials to prosecute the Work. A Notice of Non-Compliant Work in such event may be based on Article 3.3.2 (Competent Management of Time), and upon the definition of Work as set forth under Paragraph 1.1.9.58.
Obligation to Notify Owner of Existing Hazardous Materials The Contractor shall immediately notify the Owner and the Design Professional, both orally and in writing, of the presence and location of any physical evidence of, or information regarding the presence of Hazardous Materials at the Site of which it becomes aware. If the Contractor encounters Hazardous Materials on the Site the Contractor shall (i) immediately stop performance of Work or that portion of the Work affected by or affecting such Hazardous Materials; (ii) secure the contaminated area against intrusion; (iii) not disturb or remove the Hazardous Materials; (iv) not proceed, or allow any subcontractor or supplier to proceed, with any Work or other activities in the area affected by such Hazardous Materials until such materials have been properly remediated and until directed in writing to do so by the Owner; and, (v) take any other steps necessary to protect life and health and the surrounding environment. The Contractor shall be entitled to adjustment of the Contract Time and the Contract Sum pursuant to Section 5, Part 2 of these General Conditions in order to compensate for the impact of any required demolition, re-work, shutdown, delay, protection of work, disruption, and start-up resulting from the encountering of such Hazardous Materials on the Site for which the Contractor is not responsible.
FAILURE TO HONOUR SETTLEMENT AGREEMENT 32. If this Settlement Agreement is accepted by the Hearing Panel and, at any subsequent time, the Respondent fails to honour any of the Terms of Settlement set out herein, Staff reserves the right to bring proceedings under section 24.3 of the By-laws of the MFDA against the Respondent based on, but not limited to, the facts set out in Part IV of the Settlement Agreement, as well as the breach of the Settlement Agreement. If such additional enforcement action is taken, the Respondent agrees that the proceeding(s) may be heard and determined by a hearing panel comprised of all or some of the same members of the hearing panel that accepted the Settlement Agreement, if available.
Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.
