Products Products available under this Contract are limited to Software, including Software as a Service, products and related products as specified in Appendix C, Pricing Index. Vendor may incorporate changes to their product offering; however, any changes must be within the scope of products awarded based on the posting described in Section 1.B above. Vendor may not add a manufacturer’s product line which was not included in the Vendor’s response to the solicitation described in Section 1.B above.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
COVID-19 Vaccine Passports Pursuant to Texas Health and Safety Code, Section 161.0085(c), Contractor certifies that it does not require its customers to provide any documentation certifying the customer’s COVID-19 vaccination or post-transmission recovery on entry to, to gain access to, or to receive service from the Contractor’s business. Contractor acknowledges that such a vaccine or recovery requirement would make Contractor ineligible for a state-funded contract.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Borrower Products Except as described on Schedule 5.11, no Intellectual Property owned by Borrower or Borrower Product has been or is subject to any actual or, to the knowledge of Borrower, threatened litigation, proceeding (including any proceeding in the United States Patent and Trademark Office or any corresponding foreign office or agency) or outstanding decree, order, judgment, settlement agreement or stipulation that restricts in any manner Borrower’s use, transfer or licensing thereof or that may affect the validity, use or enforceability thereof. There is no decree, order, judgment, agreement, stipulation, arbitral award or other provision entered into in connection with any litigation or proceeding that obligates Borrower to grant licenses or ownership interest in any future Intellectual Property related to the operation or conduct of the business of Borrower or Borrower Products. Borrower has not received any written notice or claim, or, to the knowledge of Borrower, oral notice or claim, challenging or questioning Borrower’s ownership in any Intellectual Property (or written notice of any claim challenging or questioning the ownership in any licensed Intellectual Property of the owner thereof) or suggesting that any third party has any claim of legal or beneficial ownership with respect thereto nor, to Borrower’s knowledge, is there a reasonable basis for any such claim. Neither Borrower’s use of its Intellectual Property nor the production and sale of Borrower Products infringes the Intellectual Property or other rights of others.
Cloud storage DSHS Confidential Information requires protections equal to or greater than those specified elsewhere within this exhibit. Cloud storage of Data is problematic as neither DSHS nor the Contractor has control of the environment in which the Data is stored. For this reason:
(1) DSHS Data will not be stored in any consumer grade Cloud solution, unless all of the following conditions are met:
(a) Contractor has written procedures in place governing use of the Cloud storage and Contractor attests in writing that all such procedures will be uniformly followed.
(b) The Data will be Encrypted while within the Contractor network.
(c) The Data will remain Encrypted during transmission to the Cloud.
(d) The Data will remain Encrypted at all times while residing within the Cloud storage solution.
(e) The Contractor will possess a decryption key for the Data, and the decryption key will be possessed only by the Contractor and/or DSHS.
(f) The Data will not be downloaded to non-authorized systems, meaning systems that are not on either the DSHS or Contractor networks.
(g) The Data will not be decrypted until downloaded onto a computer within the control of an Authorized User and within either the DSHS or Contractor’s network.
(2) Data will not be stored on an Enterprise Cloud storage solution unless either:
(a) The Cloud storage provider is treated as any other Sub-Contractor, and agrees in writing to all of the requirements within this exhibit; or,
(b) The Cloud storage solution used is FedRAMP certified.
(3) If the Data includes protected health information covered by the Health Insurance Portability and Accountability Act (HIPAA), the Cloud provider must sign a Business Associate Agreement prior to Data being stored in their Cloud solution.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
Drop Shipped Off loaded by carrier to an Agency loading dock or designated area. There will be no charge to the ordering Agency for this delivery method.
Products Covered The System shall mean only the Firestone branded roofing membranes, Firestone branded roofing insulations, Firestone branded roofing metal, and other Firestone branded roofing accessories when installed in accordance with Firestone technical specifications by a Firestone-licensed applicator. Any materials not manufactured or supplied by Firestone are not covered under this Red Shield™ Roofing System Limited Warranty (“Limited Warranty”).
TOOL STORAGE 1. A company shall provide on all construction jobs in towns and cities, and elsewhere where reasonably necessary and practicable (or if requested buy the employee), a suitable and secure waterproof lock-up solely for the purpose of storing employees’ tools, and on multi-storey and major projects the company shall provide, where possible, a suitable lock-up for employees’ tools within a reasonable distance of the work area of large groups of employees.
2. Where an employee is absent from work because of illness or accident and has advised the company in accordance with Clause 33 – Personal Leave of the award, the company shall ensure that the employee’s tools are securely stored during his/her absence.
