Executive Order Minimum Wage rate (1) The Recipient shall pay to workers, while performing in the United States, and performing on, or in connection with, this agreement, a minimum hourly wage rate of $10.10 per hour beginning January 1, 2015.
PRICING for Markup of Non-Prepriced Items in RS Means Unit Price Book What is your proposed Markup Percentage on materials not found in the RS Means Price Book? If any materials being utilized for a project cannot be found in the RS Means Price Book, this question is what is the markup percentage on those materials? When answering this question please insert the number that represents your percentage of proposed markup. Example: if you are proposing a 30 percent markup, please insert the number "30". Remember that this is a ceiling markup. You may markup a lesser percentage to the TIPS Member customer when pricing the project, but not a greater percentage. EXAMPLE: You need special materials that are not in the RS Means Unit Price Book for a project. You would buy the materials and mark them up to the TIPS Member customer by the percentage you propose in this question. If the materials cost you, the contractor, $100 and you proposed a markup on this question for the material of 30 percent, then you would charge the TIPS Member customer $130 for the materials.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Minimum Wage Rates It shall include, in all contracts in excess of $2,000 for work on any projects funded under this grant agreement which involve labor, provisions establishing minimum rates of wages, to be predetermined by the Secretary of Labor, in accordance with the Xxxxx-Xxxxx Act, as amended (40 U.S.C. 276a-276a-5), which contractors shall pay to skilled and unskilled labor, and such minimum rates shall be stated in the invitation for bids and shall be included in proposals or bids for the work.
Prevailing Wage Rate Applicable to Bid Submissions A copy of the applicable prevailing wage rates to be paid or provided are annexed to the Bid Documents. Bidders must submit Bids which are based upon the prevailing hourly wages, and supplements in cash or equivalent benefits (i.e., fringe benefits and any cash or non-cash compensation which are not wages, as defined by law) that equal or exceed the applicable prevailing wage rate(s) for the location where the work is to be performed. Bidders may not submit Bids based upon hourly wage rates and supplements below the applicable prevailing wage rates as established by the New York State Department of Labor. Bids that fail to comply with this requirement will be disqualified.
Indirect Cost Rates The System Agency may acknowledge an indirect cost rate for Grantees that is utilized for all applicable contracts. Grantee will provide the necessary financial documents to determine the indirect cost rate in accordance with the Uniform Grant Guidance (UGG) and Uniform Grant Management Standards (UGMS).
Offense Level Calculations i. The base offense level is 7, pursuant to Guideline § 2B1.1(a)(1).
Cashing out of Annual Leave (a) Annual leave credited to an employee may be cashed out by agreement, subject to the following conditions: (refer to section 93 of the Act)
JOC Pricing of Itemized List of RS Means Non-Prepriced Items No response The Vendor may download the optional Pricing of Itemized List of RS Means Non-Prepriced Items form from the attachment tab, fill in the requested information, and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files. Reference Form (PARTS 1 & 2) 220107 Reference_Form.xls Valid Reference Email addresses are REQUIRED on the spreadsheet. The vendor must download the References spreadsheet from the attachment tab, fill in the requested information and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files.
Minimum Call-Back Time An employee who is called in and required to work outside their regular working hours shall be paid for a minimum of two (2) hours at overtime rates unless the call-in is immediately prior to their normal work day, in which case there should be no minimum.
