For Medium & Major Repairs written approval from the Authority’s Sample Clauses

For Medium & Major Repairs written approval from the Authority’s. Project Manager must be obtained before proceeding with the Medium or Major repair.
Sample 1
AutoNDA by SimpleDocs

Related to For Medium & Major Repairs written approval from the Authority’s

  • Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.

  • Purchaser's Election to Delay Foreclosure Proceedings (a) The Purchaser shall be deemed to direct the Company to direct (to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement) the related Servicer that in the event that the Company does not receive written notice of the Purchaser's election pursuant to subsection (b) below within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01 (a) (ii) subject to extension as set forth in Section 2.02(b), the related Servicer may proceed with the Commencement of Foreclosure in respect of such Mortgage Loan in accordance with its normal foreclosure policies without further notice to the Purchaser. Any foreclosure that has been initiated may be discontinued (i) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the related Servicer) or (ii) if the related Servicer has reached the terms of a forbearance agreement with the borrower. In the latter case, the related Servicer may complete such forbearance agreement unless instructed otherwise by the Purchaser within two Business Days notification. (b) In connection with any Mortgage Loan with respect to which a notice under Section 2.01(a)(ii) has been given to the Purchaser, the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to delay the Commencement of Foreclosure until such time as the Purchaser determines that the related Servicer may proceed with the Commencement of Foreclosure. Such election must be evidenced by written notice received within 24 hours (exclusive of any intervening non-Business Days) of transmission of the notice provided by the Company under Section 2.01(a)(ii). Such 24 hour period shall be extended for no longer than an additional four Business Days after the receipt of the information if the Purchaser requests additional information related to such foreclosure; provided, however, that the Purchaser will have at least one Business Day to respond to any requested additional information. Any such additional information shall be provided only to the extent it (i) is not confidential in nature and (ii) is obtainable by the related Servicer from existing reports, certificates or statements or is otherwise readily accessible to its servicing personnel. The Purchaser agrees that it has no right to deal with the mortgagor during such period. However, if such servicing activities include acceptance of a deed-in-lieu of foreclosure or short payoff, the Purchaser will be notified and given two Business Days to respond. (c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Purchaser shall obtain a Current Appraisal as soon as practicable, but in no event more than 15 business days thereafter, and shall provide the Company with a copy of such Current Appraisal. (d) Within two Business Days of making any Election to Delay Foreclosure, the Purchaser shall remit by wire transfer to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to the sum of (i) 125% of the greater of the unpaid principal balance of the Mortgage Loan and the value shown in the Current Appraisal referred to in subsection (c) above (or, if such Current Appraisal has not yet been obtained, the Company's estimate thereof, in which case the required deposit under this subsection shall be adjusted upon obtaining such Current Appraisal), and (ii) three months' interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If any Election to Delay Foreclosure extends for a period in excess of three months (such excess period being referred to herein as the "Excess Period"), within two Business Days the Purchaser shall remit by wire transfer in advance to the Company for deposit in the Collateral Fund the amount of each additional month's interest, as calculated by the Company, equal to interest on the Mortgage Loan at the applicable Mortgage Interest Rate for the Excess Period. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit any of the above amounts relating to the Mortgage Loan within two Business Days of the Election to Delay Foreclosure or within two Business Days of the commencement of the Excess Period subject to Section 3.01. (e) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the Company may withdraw from the Collateral Fund from time to time amounts necessary to reimburse the related Servicer for all related Monthly Advances and Liquidation Expenses thereafter made by such Servicer in accordance with the Pooling and Servicing Agreement and the related Servicing Agreement. To the extent that the amount of any such Liquidation Expenses is determined by the Company based on estimated costs, and the actual costs are subsequently determined to be higher, the Company may withdraw the additional amount from the Collateral Fund. In the event that the Mortgage Loan is brought current by the mortgagor and the foreclosure action is discontinued, the amounts so withdrawn from the Collateral Fund shall be redeposited if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. Except as provided in the preceding sentence, amounts withdrawn from the Collateral Fund to cover Monthly Advances and Liquidation Expenses shall not be redeposited therein or otherwise reimbursed to the Purchaser. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this subsection) shall be released to the Purchaser. (f) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Delay Foreclosure, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than the delay in Commencement of Foreclosure as provided herein). If and when the Purchaser shall notify the Company that it believes that it is appropriate to do so, the related Servicer may proceed with the Commencement of Foreclosure. In any event, if the Mortgage Loan is not brought current by the mortgagor by the time the loan becomes 6 months delinquent, the Purchaser's election shall no longer be effective and at the Purchaser's option, either (i) the Purchaser shall purchase the Mortgage Loan from the related Trust Estate at a purchase price equal to the fair market value as shown on the Current Appraisal, to be paid by (x) applying any balance in the Collateral Fund to such to such purchase price, and (y) to the extent of any deficiency, by wire transfer of immediately available funds from the Purchaser to the Company for deposit in the related Certificate Account; or (ii) the related Servicer shall proceed with the Commencement of Foreclosure. (g) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Delay Foreclosure and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (f) above, the Company shall calculate the amount, if any, by which the value shown on the Current Appraisal obtained under subsection (c) exceeds the actual sales price obtained for the related Mortgaged Property (net of Liquidation Expenses and accrued interest related to the extended foreclosure period), and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Purchaser's Election to Commence Foreclosure Proceedings (a) In connection with any Mortgage Loan identified in a report under Section 2.01(a)(i)(B), the Purchaser may elect to instruct the Company to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure as soon as practicable. Such election must be evidenced by written notice received by the Company by 5:00 p.m., New York City time, on the third Business Day following the delivery of such report under Section 2.01(a)(i). (b) Within two Business Days of making any Election to Foreclose, the Purchaser shall remit to the Company, for deposit in the Collateral Fund, an amount, as calculated by the Company, equal to 125% of the current unpaid principal balance of the Mortgage Loan and three months interest on the Mortgage Loan at the applicable Mortgage Interest Rate. If and when any such Mortgage Loan is brought current by the mortgagor, all amounts in the Collateral Fund in respect of such Mortgage Loan (after adjustment for all permitted withdrawals and deposits pursuant to this Agreement) shall be released to the Purchaser if and to the extent that reimbursement therefor from amounts paid by the mortgagor is not prohibited pursuant to the Pooling and Servicing Agreement or the related Servicing Agreement, applicable law or the related mortgage note. The terms of this Agreement will no longer apply to the servicing of any Mortgage Loan upon the failure of the Purchaser to deposit the above amounts relating to the Mortgage Loan within two Business Days of the Election to Foreclose subject to Section 3.01. (c) With respect to any Mortgage Loan as to which the Purchaser has made an Election to Foreclose, the related Servicer shall continue to service the Mortgage Loan in accordance with its customary procedures (other than Commencement of Foreclosure as provided herein). In connection therewith, the Company shall have the same rights to make withdrawals for Monthly Advances and Liquidations Expenses from the Collateral Fund as are provided under Section 2.02(e), and the Company shall make reimbursements thereto to the limited extent provided under such subsection in accordance with its customary procedures. The Company shall not be required to cause, to the extent that the Company as Master Servicer is granted such authority in the related Servicing Agreement, the related Servicer to proceed with the Commencement of Foreclosure if (i) the same is stayed as a result of the mortgagor's bankruptcy or is otherwise barred by applicable law, or to the extent that all legal conditions precedent thereto have not yet been complied with, or (ii) the Company believes there is a breach of representations or warranties by the Company, a Servicer, or a Seller, which may result in a repurchase or substitution of such Mortgage Loan, or (iii) the Company or related Servicer reasonably believes the Mortgaged Property may be contaminated with or affected by hazardous wastes or hazardous substances (and, without limiting the related Servicer's right not to proceed with the Commencement of Foreclosure, the Company supplies the Purchaser with information supporting such belief). Any foreclosure that has been initiated may be discontinued (x) without notice to the Purchaser if the Mortgage Loan has been brought current or if a refinancing or prepayment occurs with respect to the Mortgage Loan (including by means of a short payoff approved by the Purchaser) or (y) with notice to the Purchaser if the related Servicer has reached the terms of a forbearance agreement unless instructed otherwise by the Purchaser within two Business Days of such notification. Any such instruction shall be based upon a decision that such forbearance agreement is not in conformity with reasonable servicing practices. (d) Upon the occurrence of a liquidation with respect to any Mortgage Loan as to which the Purchaser made an Election to Foreclose and as to which the related Servicer proceeded with the Commencement of Foreclosure in accordance with subsection (c) above, the Company shall calculate the amount, if any, by which the unpaid principal balance of the Mortgage Loan at the time of liquidation (plus all unreimbursed interest and servicing advances and Liquidation Expenses in connection therewith other than those paid from the Collateral Fund) exceeds the actual sales price obtained for the related Mortgaged Property, and the Company shall withdraw the amount of such excess from the Collateral Fund, shall remit the same to the Trust Estate and in its capacity as Master Servicer shall apply such amount as additional Liquidation Proceeds pursuant to the Pooling and Servicing Agreement. After making such withdrawal, all amounts remaining in the Collateral Fund (after adjustment for all withdrawals and deposits pursuant to subsection (c) in respect of such Mortgage Loan shall be released to the Purchaser.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Regulatory and Special Allocations Notwithstanding the provisions of Section 6.1: (a) If there is a net decrease in Company Minimum Gain (determined according to Treasury Regulations Section 1.704-2(d)(1)) during any Fiscal Year, each Member shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to such Member’s share of the net decrease in Company Minimum Gain, determined in accordance with Treasury Regulations Section 1.704-2(g). The items to be so allocated shall be determined in accordance with Treasury Regulations Sections 1.704-2(f)(6) and 1.704-2(j)(2). This Section 6.2(a) is intended to comply with the “minimum gain chargeback” requirement in Treasury Regulation Section 1.704-2(f) and shall be interpreted consistently therewith. (b) Member Nonrecourse Deductions shall be allocated in the manner required by Treasury Regulations Section 1.704-2(i). Except as otherwise provided in Treasury Regulations Section 1.704-2(i)(4), if there is a net decrease in Member Nonrecourse Debt Minimum Gain during any Fiscal Year, each Member that has a share of such Member Nonrecourse Debt Minimum Gain shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to that Member’s share of the net decrease in Member Nonrecourse Debt Minimum Gain. Items to be allocated pursuant to this paragraph shall be determined in accordance with Treasury Regulations Sections 1.704-2(i)(4) and 1.704-2(j)(2). This Section 6.2(b) is intended to comply with the “minimum gain chargeback” requirements in Treasury Regulations Section 1.704-2(i)(4) and shall be interpreted consistently therewith. (c) In the event any Member unexpectedly receives any adjustments, allocations or Distributions described in Treasury Regulations Section 1.704-1(b)(2)(ii)(d)(4), (5) or (6), income and gain shall be specially allocated to such Member in an amount and manner sufficient to eliminate the Adjusted Capital Account Deficit created by such adjustments, allocations or Distributions as quickly as possible. This Section 6.2(c) is intended to comply with the qualified income offset requirement in Treasury Regulations Section 1.704-1(b)(2)(ii)(d) and shall be interpreted consistently therewith. (d) The allocations set forth in paragraphs (a), (b) and (c) above (the “Regulatory Allocations”) are intended to comply with certain requirements of the Treasury Regulations under Code Section 704. Notwithstanding any other provisions of this Article VI (other than the Regulatory Allocations), the Regulatory Allocations shall be taken into account in allocating Net Income and Net Losses among Members so that, to the extent possible, the net amount of such allocations of Net Income and Net Losses and other items and the Regulatory Allocations to each Member shall be equal to the net amount that would have been allocated to such Member if the Regulatory Allocations had not occurred. (e) The Company and the Members acknowledge that allocations like those described in Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) (“Forfeiture Allocations”) result from the allocations of Net Income and Net Loss provided for in this Agreement. For the avoidance of doubt, the Company is entitled to make Forfeiture Allocations and, once required by applicable final or temporary guidance, allocations of Net Income and Net Loss shall be made in accordance with Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) or any successor provision or guidance.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • NYISO and Connecting Transmission Owner Obligations Connecting Transmission Owner and NYISO shall cause the New York State Transmission System and the Connecting Transmission Owner’s Attachment Facilities to be operated, maintained and controlled in a safe and reliable manner in accordance with this Agreement and the NYISO Tariffs. Connecting Transmission Owner and NYISO may provide operating instructions to Developer consistent with this Agreement, NYISO procedures and Connecting Transmission Owner’s operating protocols and procedures as they may change from time to time. Connecting Transmission Owner and NYISO will consider changes to their respective operating protocols and procedures proposed by Developer.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!