Fire or Other Casualty (a) Subject to the terms and conditions of any mortgage having priority over this Lease, if the Building and Premises are damaged by fire or any other cause to such extent that the same cannot be restored, as reasonably estimated by Xxxxxxxx, within one hundred fifty (150) days after the date of such damage or destruction, then Landlord shall, no later than the sixtieth (60th) day following the damage, give Tenant notice of Landlord’s election either to (a) restore the Building and Premises (including the Landlord’s Work, but expressly excluding the Upgraded Work), or (b) terminate this Lease. In the event Landlord elects to terminate this Lease, the Lease shall terminate on the earlier of the date of such notice or the date upon which Xxxxxx surrenders possession of the Premises. In such event, the Rent and other charges due hereunder shall be apportioned as of the day following the casualty, and any Rent paid for any period beyond said date shall be repaid to Tenant. If the time of restoration as estimated by Landlord shall be less than one hundred fifty (150) days, or if Landlord does not elect to terminate this Lease, as hereinabove provided, Landlord shall restore the Building and the Premises (including the Landlord’s Work, but expressly excluding the Upgraded Work) within said one hundred fifty (150) day period, subject to Force Majeure and delays in making of insurance adjustments by Landlord, and Tenant shall have no right to terminate this Lease except as herein provided. Tenant shall, in such event, restore fixtures and improvements (including without limitation, the Upgraded Work) made by or for Tenant to the condition required by Tenant for its operations in the Premises. In the event the Building and Premises are damaged by fire or any other cause to such extent that the same cannot be restored, as reasonably estimated by Landlord, within one hundred fifty (150) days after the date of such damage or destruction, then Tenant may, provided that the such casualty was not caused by the willful misconduct or negligence of Tenant, its agents or employees, terminate this Lease and Tenant shall vacate the Premises and surrender the same to Landlord and Tenant’s liability for Rent shall cease as of the day following the casualty. If this Lease is not terminated in accordance with this Section 20, and Xxxxxxxx fails to restore the Premises and the Building such that Tenant can use and occupy the Premises for its intended purposes within one hundred eighty (180) days following such casualty event, Tenant shall have the right to terminate this Lease at any time prior to Landlord’s completion of such restoration.
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
Force Majeure Notice In relation to any Relevant Force Majeure Event:
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.
FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract.
F orce Majeure CONTRACTOR shall not be assessed with liquidated damages or unsatisfactory performance penalties during any delay beyond the time named for the performance of AGREEMENT caused by any act of God, war, civil disorder, employment strike or other cause beyond its reasonable control, provided CONTRACTOR gives written notice of the cause of the delay to COUNTY within thirty-six (36) hours of the start of the delay and CONTRACTOR avails himself of any available remedies.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
FORCE MAJEURE CLAUSE Contractor shall be excused from performance hereunder during the time and to the extent that it is prevented from obtaining delivery, or performing by act of God, fire, strike, loss, or shortage of transportation facilities, lock-out, commandeering of materials, product, plant, or facilities by the government, when satisfactory evidence thereof is presented to the District, provided that it is satisfactorily established that the non-performance is not due to the fault or neglect of Contractor.
INTERRUPTIONS TO THE TENANCY 5.3.1 To agree that Rent shall cease to be payable, if the Property is destroyed or made uninhabitable by fire, or any other risk against which the Landlord’s policy has insured, until the Property is reinstated and rendered habitable; unless the insurance monies are not recoverable (whether in whole or in part) or the damage needs to be made good because of anything done or not done by the Tenant, their family, or their visitors; or the insurer pays the costs of re-housing the Tenant. It is agreed that the Landlord has no obligation to re-house the Tenant.
Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event.
