Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Force Majeur Except with respect to obligations to make payments hereunder, neither party shall be deemed in default hereunder, nor shall it hold the other party responsible for, any cessation, interruption or delay in the performance of its obligations hereunder due to causes beyond its reasonable control including, but not limited to: earthquake, flood, fire, storm or other natural disaster, act of God, labor controversy or threat thereof, civil disturbance or commotion, disruption of the public markets, war or armed conflict or the inability to obtain sufficient material, supplies, labor, transportation, power or other essential commodity or service required in the conduct of its business, including internet access, or any change in or the adoption of any law, ordinance, rule, regulation, order, judgment or decree.
MAJEURE A party is not liable for failure to perform the party’s obligations if such failure is as a result of acts of God (including fire, flood, earthquake, storm, hurricane or other natural disaster), pandemic, war, invasion, act of foreign enemies, hostilities (regardless of whether war is declared), civil war, rebellion, revolution, insurrection, military or usurped power or confiscation, terrorist activities, nationalization, decrees of a court, tribunal or governmental authority, government sanction, blockage, embargo, labor dispute, strike, or lockout. If a party asserts any force majeure as an excuse for failure to perform, such non-performing party must prove that it took reasonable steps to minimize delay or damages caused by foreseeable events and that the other Party was timely notified of the likelihood or actual occurrence of a force majeure event. In the event of non-performance and/or termination pursuant to this Section 8.16, notwithstanding any other provision of this Agreement, the Xxxxxxx Money shall be returned to the Operating Partnership in full.
Force Majeure In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.
Force Majeure Events The Parties shall be excused from any failure to perform any obligation hereunder to the extent such failure is caused by a Force Majeure Event. A Force Majeure Event shall operate to excuse a failure to perform an obligation hereunder only for the period of time during which the Force Majeure Event renders performance impossible or infeasible and only if the Party asserting Force Majeure as an excuse for its failure to perform has provided written notice to the other Party specifying the obligation to be excused and describing the events or conditions constituting the Force Majeure Event. As used herein, “Force Majeure Event” means the occurrence of an event or circumstance beyond the reasonable control of the party failing to perform, including, without limitation, (a) explosions, fires, flood, earthquakes, catastrophic weather conditions, or other elements of nature or acts of God; (b) acts of war (declared or undeclared), acts of terrorism, insurrection, riots, civil disorders, rebellion or sabotage; (c) acts of federal, state, local or foreign governmental authorities or courts; (d) labor disputes, lockouts, strikes or other industrial action, whether direct or indirect and whether lawful or unlawful; (e) failures or fluctuations in electrical power or telecommunications service or equipment; and (f) delays caused by the other Party’s nonperformance hereunder.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
No Force Majeure Event There shall not have been any delay, error, failure or interruption in the conduct of the business of the Acquiror Company, or any loss, injury, delay, damage, distress, or other casualty, due to force majeure including but not limited to (a) acts of God; (b) fire or explosion; (c) war, acts of terrorism or other civil unrest; or (d) national emergency.
Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
