Non-Political Event A Non-Political Event shall mean one or more of the following acts or events: (a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site); (b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Bus Terminal for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 34.3; (c) any failure or delay of a Contractor but only to the extent caused by another Non-Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (d) any delay or failure of an overseas contractor to deliver rolling stock or equipment in India if such delay or failure is caused outside India by any event specified in Sub-clause (a) above and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such contractor; (e) any judgement or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority; (f) the discovery of geological conditions, toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a site inspection; or (g) any event or circumstances of a nature analogous to any of the foregoing.
Geological and archaeological finds It is expressly agreed that mining, geological or archaeological rights do not form part of this Agreement with the Contractor for the Works, and the Contractor hereby acknowledges that it shall not have any mining rights or interest in the underlying minerals, fossils, antiquities, structures or other remnants or things either of particular geological or archaeological interest and that such rights, interest and property on or under the Site shall vest in and belong to the Authority or the concerned Government Instrumentality. The Contractor shall take all reasonable precautions to prevent its workmen or any other person from removing or damaging such interest or property and shall inform the Authority forthwith of the discovery thereof and comply with such instructions as the concerned Government Instrumentality may reasonably give for the removal of such property. For the avoidance of doubt, it is agreed that any reasonable expenses incurred by the Contractor hereunder shall be reimbursed by the Authority. It is also agreed that the Authority shall procure that the instructions hereunder are issued by the concerned Government Instrumentality within a reasonable period.
Indirect Political Event An Indirect Political Event shall mean one or more of the following acts or events: (a) an act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, riot, insurrection, terrorist or military action, civil commotion or politically motivated sabotage; (b) industry-wide or State-wide strikes or industrial action for a continuous period of 24 (twenty four) hours and exceeding an aggregate period of 7 (seven) days in an Accounting Year; (c) any civil commotion, boycott or political agitation which prevents collection of Fee by the Concessionaire for an aggregate period exceeding 7 (seven) days in an Accounting Year; (d) any failure or delay of a Contractor to the extent caused by any Indirect Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; (e) any Indirect Political Event that causes a Non-Political Event; or (f) any event or circumstances of a nature analogous to any of the foregoing.
Political Activities Grant funds cannot be used for the following activities: A. Grantees and their relevant sub-grantees or subcontractors are prohibited from using grant funds directly or indirectly for political purposes, including lobbying, advocating for legislation, campaigning for, endorsing, contributing to, or otherwise supporting political candidates or parties, and voter registration campaigns. Grantees may use private, or non-System Agency money or contributions for political purposes but may not charge to, or be reimbursed from, System Agency contracts or grants for the costs of such activities. X. Xxxxx-funded employees may not use official authority or influence to achieve any political purpose and grant funds cannot be used for the salary, benefits, or any other compensation of an elected official. X. Xxxxx funds may not be used to employ, in any capacity, a person who is required by Chapter 305 of the Texas Government Code to register as a lobbyist. Additionally, grant funds cannot be used to pay membership dues to an organization that partially or wholly pays the salary of a person who is required by Chapter 305 of the Texas Government Code to register as a lobbyist. D. As applicable, Grantee will comply with 31 USC § 1352, relating to the limitation on use of appropriated funds to influence certain Federal contracting and financial transactions.
Political Activity An employee shall not use his or her official authority for the purpose of interfering with or affecting the nomination or election of any candidate for public office. An employee shall not command or solicit in a coercive fashion from any other employee direct or indirect participation in any political activity or enforce or solicit in a coercive fashion contribution for any political party, organization, or candidate. An employee shall retain his or her right to vote and freely express opinions on all political subjects. An employee shall not be prohibited from participation in local community activities or from holding public office in the community in which the employee resides, provided that such activity does not conflict with Section 3.01 of the Rules and Regulations for Personnel Administration (and the Federal Hatch Act to the extent that employees of agencies receiving federal funds are subject thereto).
Economic Sanctions None of the Company, the Sponsor, any non-independent director or officer or, to the knowledge of the Company, any independent director or director nominee, agent or affiliate of the Company is currently subject to any sanctions administered by the Office of Foreign Assets Control of the U.S. Treasury Department (“OFAC”) or any similar sanctions imposed by any other body, governmental or other, to which any of such persons is subject (collectively, “other economic sanctions”); and the Company will not directly or indirectly use the proceeds of the Offering, or lend, contribute or otherwise make available such proceeds to any subsidiary, joint venture partner or other person or entity, for the purpose of financing the activities of any person currently subject to any sanctions administered by OFAC or other economic sanctions.
Foreign Terrorist Organizations Contractor represents and warrants that it is not engaged in business with Iran, Sudan, or a foreign terrorist organization, as prohibited by Section 2252.152 of the Texas Government Code.
OFAC Sanctions None of Southwest, any Southwest Entity or any director or officer or, to the Knowledge of Southwest, any agent, employee, affiliate or other Person acting on behalf of any Southwest Entity (a) engaged in any services (including financial services), transfers of goods, software, or technology, or any other business activity related to (i) Cuba, Iran, North Korea, Sudan, Syria or the Crimea region of Ukraine claimed by Russia (“Sanctioned Countries”), (ii) the government of any Sanctioned Country, (iii) any person, entity or organization located in, resident in, formed under the laws of, or owned or controlled by the government of, any Sanctioned Country, or (iv) any Person made subject of any sanctions administered or enforced by the United States Government, including, without limitation, the list of Specially Designated Nationals (“SDN List”) of the U.S. Department of the Treasury’s Office of Foreign Assets Control (“OFAC”), or by the United Nations Security Council, the European Union, Her Majesty’s Treasury, or other relevant sanctions authority (collectively, “Sanctions”), (b) engaged in any transfers of goods, technologies or services (including financial services) that may assist the governments of Sanctioned Countries or facilitate money laundering or other activities proscribed by United States Law, (c) is a Person currently the subject of any Sanctions or (d) is located, organized or resident in any Sanctioned Country.
Political Event A Political Event shall mean one or more of the following acts or events by or on account of any Government Instrumentality: (a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 37 and its effect, in financial terms, exceeds the sum specified in Clause 37.1; (b) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Concessionaire or of the Contractors; (c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Concessionaire or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit; (d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or (e) any event or circumstance of a nature analogous to any of the foregoing.
Economic Sanctions, Etc The Company will not, and will not permit any Controlled Entity to (a) become (including by virtue of being owned or controlled by a Blocked Person), own or control a Blocked Person or (b) directly or indirectly have any investment in or engage in any dealing or transaction (including any investment, dealing or transaction involving the proceeds of the Notes) with any Person if such investment, dealing or transaction (i) would cause any holder or any affiliate of such holder to be in violation of, or subject to sanctions under, any law or regulation applicable to such holder, or (ii) is prohibited by or subject to sanctions under any U.S. Economic Sanctions Laws.
