Funding Cost Overruns Sample Clauses

Funding Cost Overruns. Subject to customary and reasonable disbursement and security requirements of Lenders and Insurers, if (i) a Cost Overrun Amount exists, (ii) no Event of Default has occurred and is continuing, and (iii) the Independent Engineer has determined that the previous amounts paid to the Turnkey Contractor under this Agreement have been used to pay for the costs of the Work in accordance with this Agreement; then, upon the request of the Turnkey Contractor, the Cost Overrun Amount shall be disbursed to be applied to the Work as directed by the Turnkey Contractor as follows, to the extent available: (a) first, by either (at Turnkey Contractor’s election) drawing on the Security to the extent available or by funding from the Turnkey Contractor up to an amount which together with previous disbursements to, by or on behalf of the Turnkey Contractor pursuant to Sections 10.4.4(a) or 10.4.5(a) or (b) shall not exceed three hundred million Dollars ($300,000,000) plus the aggregate amount of Turnkey Contractor Additional Funding Requirements; and (b) second, from the MEP Participants Additional Cost Financing, in accordance with Section 10.5.2.
Sample 1
AutoNDA by SimpleDocs

Related to Funding Cost Overruns

  • Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.

  • Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;

  • Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • LENDER'S EXPENDITURES If any action or proceeding is commenced that would materially affect Lender’s interest in the Collateral or if Borrower fails to comply with any provision of this Agreement or any Related Documents, including but not limited to Borrower’s failure to discharge or pay when due any amounts Borrower is required to discharge or pay under this Agreement or any Related Documents, Lender on Borrower’s behalf may (but shall not be obligated to) take any action that Lender deems appropriate, including but not limited to discharging or paying all taxes, liens, security interests, encumbrances and other claims, at any time levied or placed on any Collateral and paying all costs for insuring, maintaining and preserving any Collateral. All such expenditures incurred or paid by Lender for such purposes will then bear interest at the rate charged under the Note from the date incurred or paid by Lender to the date of repayment by Borrower. All such expenses will become a part of the Indebtedness and, at Lender’s option, will (A) be payable on demand; (B) be added to the balance of the Note and be apportioned among and be payable with any installment payments to become due during either (1) the term of any applicable insurance policy; or (2) the remaining term of the Note; or (C) be treated as a balloon payment which will be due and payable at the Note’s maturity.

  • Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.

  • Project Cost An updated cost spreadsheet reflecting the current forecasted cost vs. the latest approved budget vs. the baseline budget should be included in this section. One way to track project cost is to show: (1) Baseline Budget, (2) Latest Approved Budget, (3) Current Forecasted Cost Estimate, (4) Expenditures or Commitments to Date, and (5) Variance between Current Forecasted Cost and Latest Approved Budget. Line items should include all significant cost centers, such as prior costs, right-of-way, preliminary engineering, environmental mitigation, general engineering consultant, section design contracts, construction administration, utilities, construction packages, force accounts/task orders, wrap-up insurance, construction contingencies, management contingencies, and other contingencies. The line items can be broken-up in enough detail such that specific areas of cost change can be sufficiently tracked and future improvements made to the overall cost estimating methodology. A Program Total line should be included at the bottom of the spreadsheet. Narratives, tables, and/or graphs should accompany the updated cost spreadsheet, basically detailing the current cost status, reasons for cost deviations, impacts of cost overruns, and efforts to mitigate cost overruns. The following information should be provided:

  • Monthly Disbursements On or before the fifth (5th) day of each calendar month, during the design and construction of the Tenant Improvements (or such other date as Landlord may designate), Tenant shall deliver to Landlord: (i) a request for reimbursement of amounts paid to the “Contractor,” as that term is defined in Section 4.1.1 of this Tenant Work Letter, approved by Tenant, in a commercially reasonable form to be provided by Landlord, showing the schedule, by trade, of percentage of completion of the Tenant Improvements in the Premises, detailing the portion of the work completed and the portion not completed; (ii) invoices from all of “Tenant’s Agents,” as that term is defined in Section 4.1.2 of this Tenant Work Letter, for labor rendered and materials for the Premises; (iii) executed mechanic’s lien releases, as applicable, from all of Tenant’s Agents which shall comply with the appropriate provisions, as reasonably determined by Landlord, of California Civil Code Section 3262(d); and (iv) all other information reasonably requested by Landlord. Tenant’s request for payment shall be deemed Tenant’s acceptance and approval of the work furnished and/or the materials supplied as set forth in Tenant’s payment request. Within forty-five (45) days thereafter, Landlord shall deliver a check to Tenant made payable to Tenant in payment of the lesser of: (A) the amounts so requested by “tenant as set forth in this Section 2.2.3.1, above (or, subject to the terms of Section 4.2.1, below, a percentage thereof), and (B) the balance of any remaining available portion of the Tenant Improvement Allowance, provided that Landlord does not dispute any request for payment based on non-compliance of any work with the “Approved Working Drawings,” as that term is defined in Section 3.5 below, or due to any substandard work. Landlord’s payment of such amounts shall not be deemed Landlord’s approval or acceptance of the work furnished or materials supplied as set forth in Tenant’s payment request.

  • Increased Cost and Reduced Return; Capital Adequacy; Reserves on Eurodollar Rate Loans (a) If any Lender determines that as a result of the introduction of or any change in or in the interpretation of any Law, or such Lender’s compliance therewith, there shall be any increase in the cost to such Lender of agreeing to make or making, funding or maintaining Eurodollar Rate Loans or (as the case may be) issuing or participating in Letters of Credit, or a reduction in the amount received or receivable by such Lender in connection with any of the foregoing (excluding for purposes of this subsection (a) any such increased costs or reduction in amount resulting from (i) Taxes or Other Taxes (as to which Section 3.01 shall govern), (ii) changes in the basis of taxation of overall net income or overall gross income by the United States or any foreign jurisdiction or any political subdivision of either thereof under the Laws of which such Lender is organized or has its Lending Office, and (iii) reserve requirements contemplated by Section 3.04(c)), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such increased cost or reduction. (b) If any Lender determines that the introduction of any Law regarding capital adequacy or any change therein or in the interpretation thereof, or compliance by such Lender (or its Lending Office) therewith, has the effect of reducing the rate of return on the capital of such Lender or any corporation controlling such Lender as a consequence of such Lender’s obligations hereunder (taking into consideration its policies with respect to capital adequacy and such Lender’s desired return on capital), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such reduction. (c) The Borrower shall pay to each Lender, as long as such Lender shall be required to maintain reserves with respect to liabilities or assets consisting of or including Eurocurrency funds or deposits (currently known as “Eurocurrency liabilities”), additional interest on the unpaid principal amount of each Eurodollar Rate Loan equal to the actual costs of such reserves allocated to such Loan by such Lender (as determined by such Lender in good faith, which determination shall be conclusive), which shall be due and payable on each date on which interest is payable on such Loan, provided the Borrower shall have received at least 15 days’ prior notice (with a copy to the Administrative Agent) of such additional interest from such Lender. If a Lender fails to give notice 15 days prior to the relevant Interest Payment Date, such additional interest shall be due and payable 15 days from receipt of such notice.

  • Increased Cost and Reduced Return; Capital Adequacy; Reserves on Eurocurrency Rate Loans (a) If any Lender determines that as a result of the introduction of or any change in or in the interpretation of any Law, in each case after the Closing Date, or such Lender’s compliance therewith, there shall be any increase in the cost to such Lender of agreeing to make or making, funding or maintaining Eurocurrency Rate Loans or (as the case may be) issuing or participating in Letters of Credit, or a reduction in the amount received or receivable by such Lender in connection with any of the foregoing (excluding for purposes of this Section 3.04(a) any such increased costs or reduction in amount resulting from (i) Taxes or Other Taxes (as to which Section 3.01 shall govern), (ii) changes in the basis of taxation of net income or gross income (including branch profits), and franchise (and similar) taxes imposed in lieu of net income taxes, by the United States or any foreign jurisdiction or any political subdivision of either thereof under the Laws of which such Lender is organized or maintains a Lending Office, and (iii) reserve requirements contemplated by Section 3.04(c), then from time to time within fifteen (15) days after demand by such Lender setting forth in reasonable detail such increased costs (with a copy of such demand to the Administrative Agent given in accordance with Section 3.06), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such increased cost or reduction. (b) If any Lender determines that the introduction of any Law regarding capital adequacy or any change therein or in the interpretation thereof, in each case after the Closing Date, or compliance by such Lender (or its Lending Office) therewith, has the effect of reducing the rate of return on the capital of such Lender or any corporation controlling such Lender as a consequence of such Lender’s obligations hereunder (taking into consideration its policies with respect to capital adequacy and such Lender’s desired return on capital), then from time to time upon demand of such Lender setting forth in reasonable detail the charge and the calculation of such reduced rate of return (with a copy of such demand to the Administrative Agent given in accordance with Section 3.06), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such reduction within fifteen (15) days after receipt of such demand. (c) The Borrower shall pay to each Lender, (i) as long as such Lender shall be required to maintain reserves with respect to liabilities or assets consisting of or including Eurocurrency funds or deposits, additional interest on the unpaid principal amount of each Eurocurrency Rate Loan equal to the actual costs of such reserves allocated to such Loan by such Lender (as determined by such Lender in good faith, which determination shall be conclusive in the absence of manifest error), and (ii) as long as such Lender shall be required to comply with any reserve ratio requirement or analogous requirement of any other central banking or financial regulatory authority imposed in respect of the maintenance of the Commitments or the funding of the Eurocurrency Rate Loans, such additional costs (expressed as a percentage per annum and rounded upwards, if necessary, to the nearest five decimal places) equal to the actual costs allocated to such Commitment or Loan by such Lender (as determined by such Lender in good faith, which determination shall be conclusive absent manifest error) which in each case shall be due and payable on each date on which interest is payable on such Loan, provided the Borrower shall have received at least fifteen (15) days’ prior notice (with a copy to the Administrative Agent) of such additional interest or cost from such Lender. If a Lender fails to give notice fifteen (15) days prior to the relevant Interest Payment Date, such additional interest or cost shall be due and payable fifteen (15) days from receipt of such notice. (d) Failure or delay on the part of any Lender to demand compensation pursuant to this Section 3.04 shall not constitute a waiver of such Lender’s right to demand such compensation, provided that the Borrower shall not be required to compensate a Lender pursuant to Section 3.04(a), (b) or (c) for any such increased cost or reduction incurred more than one hundred and eighty (180) days prior to the date that such Lender demands, or notifies the Borrower of its intention to demand, compensation therefor, provided further that, if the circumstance giving rise to such increased cost or reduction is retroactive, then such 180-day period referred to above shall be extended to include the period of retroactive effect thereof. (e) If any Lender requests compensation under this Section 3.04, then such Lender will, if requested by the Borrower, use commercially reasonable efforts to designate another Lending Office for any Loan or Letter of Credit affected by such event; provided that such efforts are made on terms that, in the sole judgment of such Lender, cause such Lender and its Lending Office(s) to suffer no economic, legal, regulatory or other disadvantage, and provided further that nothing in this Section 3.04(e) shall affect or postpone any of the Obligations of the Borrower or the rights of such Lender pursuant to Section 3.04(a), (b), (c) or (d).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!