Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Assistance in Litigation or Administrative Proceedings Covered Entity shall provide written notice to Business Associate if litigation or administrative proceeding is commenced against Covered Entity, its directors, officers, or employees, based on a claimed violation by Business Associate of HIPAA, the HIPAA Rules or other laws relating to security and privacy or PHI. Upon receipt of such notice and to the extent requested by Covered Entity, Business Associate shall, and shall cause its employees, Subcontractors, or agents assisting Business Associate in the performance of its obligations under the Contract to, assist Covered Entity in the defense of such litigation or proceedings. Business Associate shall, and shall cause its employees, Subcontractor’s and agents to, provide assistance, to Covered Entity, which may include testifying as a witness at such proceedings. Business Associate or any of its employees, Subcontractors or agents shall not be required to provide such assistance if Business Associate is a named adverse party.
Time Limit for Claims No Indemnified Party may make a Claim for indemnification under Section 6.1 in respect of any Claim unless notice in writing of the Claim, incorporating a statement setting out in reasonable detail the grounds on which the Claim is based, has been given by the Indemnified Party prior to the expiration of the applicable Survival Period as set forth in Part VI of Appendix B.
Litigation and Claims No litigation, claim, investigation, administrative proceeding or similar action (including those for unpaid taxes) against Borrower is pending or threatened, and no other event has occurred which may materially adversely affect Borrower’s financial condition or properties, other than litigation, claims, or other events, if any, that have been disclosed to and acknowledged by Lender in writing.
Claims Plus Claims Plus is a service that provides notice to Registrars that a domain name they are trying to register matches a trademark registered in a trademark database used by the Registry Operator.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Errors, Questions, and Complaints a. In case of errors or questions about your transactions, you should as soon as possible contact us as set forth in Section 6 of the General Terms above.
b. If you think your periodic statement for your account is incorrect or you need more information about a transaction listed in the periodic statement for your account, we must hear from you no later than sixty (60) days after we send you the applicable periodic statement for your account that identifies the error. You must:
1. Tell us your name;
2. Describe the error or the transaction in question, and explain as clearly as possible why you believe it is an error or why you need more information; and,
3. Tell us the dollar amount of the suspected error.
c. If you tell us orally, we may require that you send your complaint in writing within ten (10) Business Days after your oral notification. Except as described below, we will determine whether an error occurred within ten (10) Business Days after you notify us of the error. We will tell you the results of our investigation within three (3) Business Days after we complete our investigation of the error, and will correct any error promptly. However, if we require more time to confirm the nature of your complaint or question, we reserve the right to take up to forty-five (45) days to complete our investigation. If we decide to do this, we will provisionally credit your Eligible Transaction Account within ten (10) Business Days for the amount you think is in error. If we ask you to submit your complaint or question in writing and we do not receive it within ten (10) Business Days, we may not provisionally credit your Eligible Transaction Account. If it is determined there was no error we will mail you a written explanation within three (3) Business Days after completion of our investigation. You may ask for copies of documents used in our investigation. We may revoke any provisional credit provided to you if we find an error did not occur.
No Actions, Claims, Etc As of the date hereof, each of the Loan Parties hereby acknowledges and confirms that it has no knowledge of any actions, causes of action, claims, demands, damages and liabilities of whatever kind or nature, in law or in equity, against the Administrative Agent, the Lenders, or the Administrative Agent’s or the Lenders’ respective officers, employees, representatives, agents, counsel or directors arising from any action by such Persons, or failure of such Persons to act under the Credit Agreement on or prior to the date hereof.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
