Limitations on Authority The authority of the Board over the conduct of the business affairs of the Company shall be subject only to such limitations as are expressly stated in this Agreement or in the Act.
Due Organization, Authorization Power and Authority. Borrower and each of its Subsidiaries is duly existing and in good standing as a Registered Organization in its jurisdictions of organization or formation and Borrower and each of its Subsidiaries is qualified and licensed to do business and is in good standing in any jurisdiction in which the conduct of its businesses or its ownership of property requires that it be qualified except where the failure to do so could not reasonably be expected to have a Material Adverse Change. In connection with this Agreement, Borrower and each of its Subsidiaries has delivered to Collateral Agent a completed perfection certificate signed by an officer of Borrower or such Subsidiary (each a “Perfection Certificate” and collectively, the “Perfection Certificates”). Borrower represents and warrants that (a) Borrower and each of its Subsidiaries’ exact legal name is that which is indicated on its respective Perfection Certificate and on the signature page of each Loan Document to which it is a party; (b) Borrower and each of its Subsidiaries is an organization of the type and is organized in the jurisdiction set forth on its respective Perfection Certificate; (c) each Perfection Certificate accurately sets forth each of Borrower’s and its Subsidiaries’ organizational identification number or accurately states that Borrower or such Subsidiary has none; (d) each Perfection Certificate accurately sets forth Borrower’s and each of its Subsidiaries’ place of business, or, if more than one, its chief executive office as well as Borrower’s and each of its Subsidiaries’ mailing address (if different than its chief executive office); (e) Borrower and each of its Subsidiaries (and each of its respective predecessors) have not, in the past five (5) years, changed its jurisdiction of organization, organizational structure or type, or any organizational number assigned by its jurisdiction; and (f) all other information set forth on the Perfection Certificates pertaining to Borrower and each of its Subsidiaries, is accurate and complete (it being understood and agreed that Borrower and each of its Subsidiaries may from time to time update certain information in the Perfection Certificates (including the information set forth in clause (d) above) after the Effective Date to the extent permitted by one or more specific provisions in this Agreement); such updated Perfection Certificates subject to the review and approval of Collateral Agent. If Borrower or any of its Subsidiaries is not now a Registered Organization but later becomes one, Borrower shall notify Collateral Agent of such occurrence and provide Collateral Agent with such Person’s organizational identification number within five (5) Business Days of receiving such organizational identification number. The execution, delivery and performance by Borrower and each of its Subsidiaries of the Loan Documents to which it is a party have been duly authorized, and do not (i) conflict with any of Borrower’s or such Subsidiaries’ organizational documents, including its respective Operating Documents, (ii) contravene, conflict with, constitute a default under or violate any material Requirement of Law applicable thereto, (iii) contravene, conflict or violate any applicable order, writ, judgment, injunction, decree, determination or award of any Governmental Authority by which Borrower or such Subsidiary, or any of their property or assets may be bound or affected, (iv) require any action by, filing, registration, or qualification with, or Governmental Approval from, any Governmental Authority (except such Governmental Approvals which have already been obtained and are in full force and effect) or are being obtained pursuant to Section 6.1(b), or (v) constitute an event of default under any material agreement by which Borrower or any of such Subsidiaries, or their respective properties, is bound. Neither Borrower nor any of its Subsidiaries is in default under any agreement to which it is a party or by which it or any of its assets is bound in which such default could reasonably be expected to have a Material Adverse Change.
Information Authorization Your enrollment in the applicable Service may not be fulfilled if we cannot verify your identity or other necessary information. Through your enrollment in or use of each Service, you agree that we reserve the right to request a review of your credit rating at our own expense through an authorized bureau. In addition, and in accordance with our Privacy Policy, you agree that we reserve the right to obtain personal information about you, including without limitation, financial information and transaction history regarding your Eligible Transaction Account. You further understand and agree that we reserve the right to use personal information about you for our and our Service Providers’ everyday business purposes, such as to maintain your ability to access the Service, to authenticate you when you log in, to send you information about the Service, to perform fraud screening, to verify your identity, to determine your transaction limits, to perform collections, to comply with laws, regulations, court orders and lawful instructions from government agencies, to protect the personal safety of subscribers or the public, to defend claims, to resolve disputes, to troubleshoot problems, to enforce this Agreement, to protect our rights and property, and to customize, measure, and improve the Service and the content and layout of the Site. Additionally, we and our Service Providers may use your information for risk management purposes and may use, store and disclose your information acquired in connection with this Agreement as permitted by law, including (without limitation) any use to effect, administer or enforce a transaction or to protect against or prevent actual or potential fraud, unauthorized transactions, claims or other liability. We and our Service Providers shall have the right to retain such data even after termination or expiration of this Agreement for risk management, regulatory compliance, or audit reasons, and as permitted by applicable law for everyday business purposes. In addition, we and our Service Providers may use, store and disclose such information acquired in connection with the Service in statistical form for pattern recognition, modeling, enhancement and improvement, system analysis and to analyze the performance of the Service. The following provisions in this Section apply to certain Services:
Execution Authorized The execution, delivery and performance of this Agreement by Securities Intermediary have been duly authorized by all necessary corporate action on the part of Securities Intermediary.
Limitation on Authority A. Grantee shall not have any authority to act for or on behalf of the System Agency or the State of Texas except as expressly provided for in the Grant Agreement; no other authority, power, or use is granted or implied. Grantee may not incur any debt, obligation, expense, or liability of any kind on behalf of System Agency or the State of Texas.
B. Grantee may not rely upon implied authority and is not granted authority under the Grant Agreement to:
i. Make public policy on behalf of the System Agency;
ii. Promulgate, amend, or disregard administrative regulations or program policy decisions made by State and federal agencies responsible for administration of a System Agency program; or
iii. Unilaterally communicate or negotiate with any federal or state agency or the Texas Legislature on behalf of the System Agency regarding System Agency programs or the Grant Agreement. However, upon System Agency request and with reasonable notice from System Agency to the Grantee, the Grantee shall assist the System Agency in communications and negotiations regarding the Work under the Grant Agreement with state and federal governments.
Corporation Authorization The execution, delivery and performance by Parent of this Agreement and the consummation by Parent of the transactions contemplated hereby are within the corporate powers of Parent and have been duly authorized by all necessary corporate action. This Agreement constitutes a valid and binding agreement of Parent.
Organization; Authority Such Purchaser is either an individual or an entity duly incorporated or formed, validly existing and in good standing under the laws of the jurisdiction of its incorporation or formation with full right, corporate, partnership, limited liability company or similar power and authority to enter into and to consummate the transactions contemplated by the Transaction Documents and otherwise to carry out its obligations hereunder and thereunder. The execution and delivery of the Transaction Documents and performance by such Purchaser of the transactions contemplated by the Transaction Documents have been duly authorized by all necessary corporate, partnership, limited liability company or similar action, as applicable, on the part of such Purchaser. Each Transaction Document to which it is a party has been duly executed by such Purchaser, and when delivered by such Purchaser in accordance with the terms hereof, will constitute the valid and legally binding obligation of such Purchaser, enforceable against it in accordance with its terms, except: (i) as limited by general equitable principles and applicable bankruptcy, insolvency, reorganization, moratorium and other laws of general application affecting enforcement of creditors’ rights generally, (ii) as limited by laws relating to the availability of specific performance, injunctive relief or other equitable remedies and (iii) insofar as indemnification and contribution provisions may be limited by applicable law.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Reliance upon Authority Prior to the Closing Date, the Borrowers shall deliver to the Agent, a notice setting forth the account of the Borrowers (“Designated Account”) to which the Agent is authorized to transfer the proceeds of the Revolving Loans requested hereunder. The Borrowers may designate a replacement account from time to time by written notice. All such Designated Accounts must be reasonably satisfactory to the Agent. The Agent is entitled to rely conclusively on any person’s request for Revolving Loans on behalf of the Borrowers, so long as the proceeds thereof are to be transferred to the Designated Account. The Agent has no duty to verify the identity of any individual representing himself or herself as a person authorized by the Borrowers to make such requests on its behalf.
Organization; Authority; Enforceability (a) Each of the SPAC and Merger Sub is a corporation and is duly incorporated, validly existing and in good standing under the Laws of the State of Delaware.
(b) The SPAC Parties have all the requisite corporate power and authority to own, lease and operate their respective assets and properties and to carry on their respective businesses as presently conducted in all respects.
(c) Each SPAC Party is duly qualified, licensed or registered to do business under the Laws of each jurisdiction in which the conduct of its business or location of its assets and/or properties makes such qualification necessary, except where the failure to be so qualified would not, individually or in the aggregate, reasonably be expected to be material to the SPAC Parties, taken as a whole.
(d) No SPAC Party is in violation of any of its Governing Documents. No SPAC Party is the subject of any bankruptcy, dissolution, liquidation, reorganization or similar proceeding.
(e) Each SPAC Party has the requisite corporate power and authority to execute and deliver this Agreement and the Ancillary Agreements to which it is or will be a party and to perform its obligations hereunder and thereunder, and, subject to the receipt of the Required Vote approving the Required SPAC Stockholder Voting Matters, to consummate the Transactions. The execution, delivery and performance of this Agreement and the Ancillary Agreements and, subject to the receipt of the Required Vote approving the Required SPAC Stockholder Voting Matters, the consummation of the Transactions, have been duly authorized by all necessary corporate actions, as applicable, including by the SPAC Board and the board of directors of Merger Sub. This Agreement has been (and each of the Ancillary Agreements to which any SPAC Party is or will be a party is or will be) duly executed and delivered by such SPAC Party and are or will be Enforceable against such SPAC Party. No other corporate actions on the part of any SPAC Party, except for the Required Vote approving the Required SPAC Stockholder Voting Matters, are necessary to approve and authorize the execution, delivery or performance of this Agreement and the Ancillary Agreements or the consummation of the Transactions.
(f) A correct and complete copy of the Governing Documents of the SPAC, as in effect on the Execution Date, are filed as (i) Exhibit 3.1 to the SPAC’s Form 8-K filed with the SEC on January 24, 2022, as amended with an amendment filed as Exhibit 10.11 to the SPAC’s Form 8-K filed with the SEC on April 21, 2023, and (ii) Exhibit 3.4 to the Form S-1 filed with the SEC on August 6, 2021.
